Page 6 - Reedley Exponent 2-15-18 E-edition

A6
C6
THE REEDLEY EXPONENT Thursday, February 15, 2018
PUBLIC NOTICES
NOTICE TO BIDDERS
NOTICE IS HEREBY GIVEN that Kings Canyon Uni ed School District (hereinafter referred to as “Owner”) will re- ceive sealed bids prior to the date and time stated for the
Bid Opening for: Bid No. 0218-1712 –
RE-ROOFING AT CITRUS MIDDLE SCHOOL AND LIN-
as per drawings and speci cations which are available on our website at http://goo.gl/a8j9OM.
PLACE FOR SUBMITTING BIDS: Sealed bids must be re- ceived on March 1, 2018 prior to 10:00 a.m., at the Kings Canyon Uni ed School District, District Operations Cen- ter Conference Room located at 1502 I Street, Reedley CA, 93654. For information, contact Monica Sanchez at KCUSD Purchasing Department, phone (559) 305-7037 or email sanchez-mo@kcusd.com. Facsimile (FAX) cop- ies of the bid will not be accepted.
The lowest bid shall be determined: On the amount of the base bid. Time of completion for this Project shall be by August 10, 2018.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Indus- trial Relations. A contractor or subcontractor shall not be quali ed to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code sec- tion 4104 unless currently registered and quali ed under Labor Code section 1725.5 to perform public work as de- ned by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code. A contractor or subcontractor shall not be quali ed to enter into, or engage in the performance of, any contract of public work (as de ned by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code) unless currently registered and quali ed under Labor Code sec- tion 1725.5 to perform public work.
tract Sum, said bonds to be secured from Admitted Surety insurers (an insurance organization authorized by the Insurance Commissioner to transact business of insur- ance in the State of California during this calendar year). The surety insurers must, unless otherwise agreed to by Owner in writing, at the time of issuance of the bonds, have a rating not lower than “A-” as rated by A.M. Best Company, Inc. or other independent rating companies. Owner reserves the right to approve or reject the surety insurers selected by the successful bidder and to require the successful bidder to obtain bonds from surety insurers satisfactory to the Owner. The bidder will be required to furnish insurance as set forth in the Contract Documents. The successful bidder will be allowed to substitute securi- ties or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and Gen- eral Conditions.
The Owner will not consider or accept any bids from con- tractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bid- der shall have a Class “C-39” license and shall maintain that license in good standing through Project completion and all applicable warranty periods. Bidder shall state the California contractor license number on the Designation of Subcontractors form for all subcontractors doing more than one-half of one percent (0.5%) of the bidder’s total bid. An inadvertent error in listing a California contrac- tor’s license number shall not be grounds for ling a bid protest or for considering the bid nonresponsive if the bid- der submits the corrected contractor’s license number to the Owner within 24 hours after the bid opening, or any continuation thereof, so long as the corrected contractor’s license number corresponds to the submitted name and location for that subcontractor.
Subcontractors shall maintain their licenses in good stand- ing through Project completion and all applicable warranty periods. Owner reserves the right to reject any bid as non- responsive if bidder or any subcontractor is not licensed in good standing from the time the bid is submitted to Owner up to award of the Contract, whether or not the bidder listed the subcontractor inadvertently, or if a listed subcon- tractor’s license is suspended or expires prior to award of the Contract. Owner also reserves the right to reject any bid as non-responsive if a listed subcontractor’s license is not in good standing to perform the work for which it is listed from the time of submission of the bidder’s bid to award of the Contract.
The Owner reserves the right to waive any irregularity and to reject any or all bids. Unless otherwise required by law, no bidder may withdraw its bid for a period of sixty (60) days after the date set for the opening thereof or any authorized postponement thereof. The Owner reserves the right to take more than sixty (60) days to make a deci- sion regarding the rejection of bids or the award of the Contract.
COLN ELEMENTARY
Bids must be accompanied by a bidder’s bond, cashier’s check, or certi ed check for at least ten percent (10%) of the amount of the base bid to cover all sections bidder is bidding and made payable to the Owner. If a bid bond is used, it must be issued by an Admitted Surety (an insur- ance organization authorized by the Insurance Commis- sioner to transact surety insurance in the State of Cali- fornia during this calendar year), which shall be given as a guarantee that the bidder will enter into a Contract if awarded the Work and will be declared forfeited, paid to, or retained by the Owner as liquidated damages if the bid- der refuses or neglects to enter into the Contract provided by the Owner after being requested to do so. The surety insurer must, unless otherwise agreed to by Owner in writ- ing, at the time of issuance of the bond, have a rating not lower than “A-” as rated by A.M. Best Company, Inc. or other independent rating companies. Owner reserves the right to approve or reject the surety insurer selected by Contractor and to require Contractor to obtain a bond from a surety insurer satisfactory to the Owner.
MANDATORY PRE-BID CONFERENCE AND SITE VIS- IT: The pre-bid conference and site visits will be at Citrus Middle School, 1400 Anchor Avenue, Orange Cove, CA 93654 and beginning at 10:00 am on February 16, 2018. Attendance is mandatory, bidders not attending the con- ferences will be disquali ed from bidding on any section. Pursuant to the Contract Documents, the successful bid- der will be required to furnish a Payment (Labor and Mate- rial) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Con-
John G. Campbell, Superintendent
February 8, 15, 2018
NOTICE TO CONTRACTORS
Notice is hereby given that Kings Canyon Uni ed School District (hereinafter referred to as “Owner”) has issued notice to contractors calling for Prequali cation Applica- tions for General Contractors. Those Contractors who have been Prequali ed will receive a copy of Request for Proposal (RFP)for Lease-Lease Back Services for each project and will be eligible to submit a proposal for each Lease-Lease Back Project. The District intends to award separate contracts for each project to the contractor deter- mined to be the best value under the provisions of Educa- tion Code 17406 et seq.
Those contractors who’s Prequali cation expires during any release of RFP will not be able to submit a proposal. Contractor must be prequali ed as of the date the respec- tive proposal is due.
California Assembly Bill (AB) 1565 went into effect on Jan- uary 1, 2014. AB 1565 requires ALL General Contractors and M/E/P Subcontractors be prequali ed, if the contract is valued at $1 million or more and funded whole or in part with State Facility Bond funds. This applies to the follow- ing license numbers:
•General Contractors (A and B)
•Mechanical, Engineering, and Plumbing subcontractors (“MEPs”): C-4, C-7, C-10, C-16, C-20, C-34, C-36, C-38, C-42, C-43, and C-46
The list below identi es the potential projects that General Contractors will prequalify for. These projects are antici- pated to begin the Summer of 2018.
Jefferson Shade Structure Install
Jefferson Modernization Project
Orange Cove High School- Sport Field & Lighting Im- provement
Dunlap Leadership Academy Parking Lot Repaving Riverview Parking Lot Project
Great Western Modernization of Multipurpose Build- ing
Dunlap Modernization of Classrooms
Jefferson Of ce & 500 Building Project
Lincoln Lighting Project
Reedley High School- Ag Science Modernization Marquee Upgrades
The District reserves the right to cancel or combine any of the above listed projects.
To view and download a prequali cation questionnaire, go to www.kcusd.com and go to Departments >>Purchas- ing and Warehouse>>Prequali cation and click on the ap- plication link at the bottom.
Owner will receive applications no later than February 28, 2018 by 5:00 p.m. on the clock designated by the Owner or its representative as the governing clock, at:
Kings Canyon Uni ed School District
Attention: Monica Sanchez
1502 I Street
Reedley CA 93654
If a contractor has not already been prequali ed by the Owner, Owner will not accept the contractor’s proposal. Each prequali ed contractor who intends to submit a proposal must also submit the Prequali cation Certi ca- tion as part of the sealed proposal certifying under oath that the contractor’s responses in its initial prequali ca- tion submission continue to be true and correct. If any
of the contractor’s answers to the prequali cation ap- plication have changed since submitting the completed prequali cation application, then the proposing contractor must specify which answers have changed and provide amended answers to the District with the Prequali cation Certi cation.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Indus- trial Relations. A contractor or subcontractor shall not be quali ed to submit a proposal or to be listed in a proposal subject to the requirements of Public Contract Code sec- tion 4104 unless currently registered and quali ed under Labor Code section 1725.5 to perform public work as de- ned by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code. A contractor or subcontractor shall not be quali ed to enter into, or engage in the performance of, any contract of public work (as de ned by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code) unless currently registered and quali ed under Labor Code sec- tion 1725.5 to perform public work.
Pursuant to the Contract Documents, the successful contractor will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred per- cent (100%) of the Total Sublease Amount, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Total Sublease Amount, said bonds to be secured from Admitted Surety insurers (an insurance or- ganization authorized by the Insurance Commissioner to transact business of insurance in the State of California during this calendar year). The surety insurers must, un- less otherwise agreed to by Owner in writing, at the time of issuance of the bonds, have a rating not lower than “A-” as rated by A.M. Best Company, Inc. or other independent rating companies. Owner reserves the right to approve or reject the surety insurers selected by the successful con- tractor and to require the successful contractor to obtain bonds from surety insurers satisfactory to the Owner. The contractor will be required to furnish insurance as set forth in the Contract Documents.
The successful contractor will be allowed to substitute securities or establish an escrow in lieu of retainage, pur- suant to Public Contract Code Section 22300, and as de- scribed in the General Conditions.
The Owner will not consider or accept any proposals from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of con- tractors. In accordance with Section 3300 of said Code, the contractor shall maintain that license in good stand- ing through project completion and all applicable warranty periods.
Sub-contractors must be prequali ed at least ten business days prior to bid opening.
The Director of Industrial Relations of the State of Califor- nia, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for le- gal holidays and overtime work. The Contractor must pay for any labor therein described or classi ed in an amount not less than the rates speci ed. Copies of the required rates are on le at the Owner’s business of ce and are available to any interested party on request.
February 8, 15, 2018
Public Notice NOTICE OF PUBLIC SALE OF PERSONAL PROPERTY NOTICE IS HEREBY GIVEN that the undersigned intends to sell the personal property described below to enforce a lien imposed on said property pursuant to Sections 21700- 21716 of the Business and Professions Code, Section 2328 of the UCC,
Section 535 of the Penal Code and provisions of the Civil Code.
The undersigned, on behalf of Heritage Self Storage, 1885 E. Dinuba, Reedley, CA 93654 will sell at a public sale, by competitive bidding on Thursday, February 22nd, 2018, on www.storagetreasures. com, the following delinquent tenant’s items are described as misc.,
furniture, household items, and boxes and/ or totes of contents unknown.
Edilberto A. Juarez UNIT 1321
Purchases must be paid in cash.
All purchased items sold as is, where is, and must be removed. Sale subject to cancellation in the event of settlement between owner and
obligated party.
Dated this 7th day of February 2018 Auctioneer: www. storagetreasures.com, (480) 397-6503
February 8, 15, 2018
ADVERTISEMENT OF SALE NOTICE IS HEREBY GIVEN that the undersigned intends to sell the personal property
described below pursuant to section 21702 of the Government Code. The undersigned will sell at public sale by competitive bidding on the 28th of February, 2018 on the premises of said property has been stored and which are located at Lock and Leave Self Storage, 344 E. Dinuba Ave., Reedley, CA 93654 County of Fresno; State of California, sale
begins at 10:00 am. Sandra Cabello
Justin Houle
Jessica Ham
Richard Garcia
Maria Rubalcaba PROPERTY TO BE SOLD AS DESCRIBES AS: Loveseat, couches, baby walker, chair, television, vacuum, mirrors, cordless air compressor, satellite, 2 computer modems, TV trays, pictures, big pot, tire, rims, blanket, baby strollers, dream catcher, straw hats, tennis shoes, VCR tapes, Bird cage, mattress and box spring, baby furniture, toys, desk, dresser, clothing, rugs, hutch, miscellaneous boxes, bags, and totes. Purchases must be paid for in cash at time of the auction. All purchased items are sold as is, where is, and must be romped at the time of the sale. Sale is subject to cancellation in the event of settlement between owner and obligated party. This auction is held with “reserve” dated this 28th of February, 2018 Auctioneer:
Storage Auction Experts (209) 667-5797
February 15, 22, 2018
ORDER TO SHOW CAUSE FORCHANGE OF NAME
CASE NUMBER:
18 CE CG 00204
TO ALL INTERESTED
PERSONS:
Petitioner: filed a petition with this court for a decree changing name as follows: Present Name
Juan Ortiz
Proposed Name
Johnny Joey Romo
THE COURT ORDERS that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.
NOTICE OF HEARING
a. Date: March 5, 2018 Time: 8:30 AM Dept.:404 b. The address of the court Civil Division
1130 O Street
Fresno CA 93724
A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this count: The Reedley Exponent P.O. Box 432, Reedley, CA 93654 (559) 638-2244
Date: January 22, 2018 Signed /s/ Mark E. Cullers Judge of the Superior Court February 1, 8, 15, 22, 2018
NOTICE OF PETITION TO ADMINISTER ESTATE OF RUMALDO V. REYES CASE NO. 18CEPR00072 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of:
RUMALDO V. REYES
A Petition for Probate has been filed by: Guadalupe Lewis, also known as Mary Lewis and Maria Guadalupe Warren in the Superior Court of California, County of FRESNO.
The Petition for probate requests that Guadalupe Lewis, also known as Mary Lewis and Maria Guadalupe Warren be appointed as personal representative to administer the estate of the decedent. The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court.
The petition requests
authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: March 13, 2018 Time: 9:00 am
Dept.: 303
Address of court: 1130 "O" Street, Fresno, California 93721 B. F. Sisk Courthouse
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for petitioner: Mark S. Poochigian. BAKER MANOCK & JENSEN, PC 5260 N. Palm Avenue, Suite 421
Fresno, CA 93704 559.432.5400
February 1, 8, 15, 2018
SUPERIOR COURT OF CALIFORNIA COUNTY OF FRESNO NOTICE TO CREDITORS [Probate Section 19050] Case No. 18CEPR00113 In re the Habegger Family Trust Dated March 18, 1994 By Marianna Habegger,
Decedent
Notice is hereby given to the creditors and contingent creditors of the above- named decedent that all persons having claims against the decedent are required to file them with the Superior Court, at 1100 Van Ness Avenue, Fresno, California, 93724- 0002, and mail or deliver a copy to Randy M. Long, Attorney for the Trustee of the Habegger Family Trust Dated March 18, 1994 By Marianna Habegger, Decedent of which the decedent was the grantor, at 1756 11th Street, Reedley, California, 93654, within the later of four months after February 8, 2018, or if notice is mailed or personally delivered to you, 30 days after the date this notice is mailed or personally delivered to you, or you must file a petition of file a late claim as provided in Section 19103 of the Probate Code. A claim form may be obtained from the court clerk. For your protection, you are
encouraged to file your claim by certified mail, with return receipt requested. Date: January 31, 2018 Signed /s/ Randy M Long, Attorney for the Trustee of the Habegger Family Trust Dated March 18, 1994 By Marianna Habegger, Decedent 1756 11th Street, Reedley, CA 93654
February 8, 15, 22, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000021 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
In House Supportive Security Services 4256 W. Cortland Avenue,
Fresno, CA 93722, Fresno County Phone (559) 800-5999
Full Name of Registrant
Marty Curtis McClintock Jr.
4256 W. Cortland Avenue,
Fresno, CA 93722 Registrant commenced to transact business under the Fictitious Business Name listed above on October
23, 2017.
This business conducted by: Individual
Type or Print Signature and Title
Marty Curtis McClintock Jr., Owner
Filed with the Fresno County Clerk on: January 2, 2018
Brandi L. Orth, County Clerk
By: Alisa Sanders, Deputy Notice: This Statement Expires On: January 1, 2023
A new statement must be filed prior to the expiration date.
January 25, February 1, 8, 15, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000413 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
99 North Design & Remodel 22849 E. Jefferson, Reedley, CA 93654 Fresno County Phone (559) 393-3689
Mailing Address
22849 E. Jefferson,
Reedley, CA 93654
Full Name of Registrant
Ben A. Perez III 22849 E. Jefferson, Reedley, CA 93654 Registrant has not yet commenced to transact business under the Fictitious Business Name
listed above.
This business conducted by: Individual
Type or Print Signature and Title
Ben A. Perez III, Owner Filed with the Fresno County Clerk on: January 19, 2018
Brandi L. Orth, County Clerk
By: Gloria Ayala, Deputy Notice: This Statement Expires On: January 18, 2023
A new statement must be filed prior to the expiration date.
January 25, February 1, 8, 15, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000144 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Sanicol LLC 5588 N. Palm Ave Suite 106, Fresno, CA 93705, Fresno County Phone (888) 233-9633
Mailing Address
PO Box 7683, Fresno, CA 93747
Full Name of Registrant
Sanicol LLC
5588 N. Palm Ave Suite 106, Fresno, CA 93705 Registrant commenced to transact business under the Fictitious Business Name listed above on January 8,
2018.
This business conducted by: A Limited Liability Company
Articles of Incorporation 201735210047
Type or Print Signature and Title
Christopher Garcia Powell Jr., Member
Filed with the Fresno County Clerk on: January 8, 2018
Brandi L. Orth, County Clerk
By: Alisa Sanders, Deputy Notice: This Statement Expires On: January 7, 2023
A new statement must be filed prior to the expiration
date.
January 25,
February 1, 8, 15, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000493 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Chow’s Kitchen 1800 Marion Street, Kingsburg, CA 93631 Fresno County Phone (559) 897-8838
Full Name of Registrant
Xue Qin Wang 2261 14th Avenue Apt. #106, Kingsburg, CA 93631 Registrant has not yet commenced to transact business under the Fictitious Business Name
listed above.
This business conducted by: Individual
Type or Print Signature and Title
Xue Qin Wang, Owner Filed with the Fresno County Clerk on: January 24, 2018
Brandi L. Orth, County Clerk
By: Alisa Sanders, Deputy Notice: This Statement Expires On: January 23, 2023
A new statement must be filed prior to the expiration date.
February 1, 8, 15, 22, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000291 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Leo Blendz Barbershop 1312 11th Street, Reedley, CA 93654 Fresno County
Mailing Address
1685 N. Cedar Avenue, Reedley, CA 93654 Full Name of Registrant
Leonardo Estrada Espinoza
1685 N. Cedar Avenue, Reedley, CA 93654 Registrant commenced to transact business under the Fictitious Business Name listed above on January
16, 2018.
This business conducted by: Individual
Type or Print Signature and Title
Leonardo Estrada Espinoza, Owner
Filed with the Fresno County Clerk on: January 16, 2018
Brandi L. Orth, County Clerk
By: Sao Yang, Deputy Notice: This Statement Expires On: January 15, 2023
A new statement must be filed prior to the expiration date.
February 1, 8, 15, 22, 2018
FICTITIOUS BUSINESS NAME STATEMENT File No. 2201810000481 The Following Person is Conducting Business as
New Filing
Fictitious Business Names:
Mercantile Distributing Inc. MDI
1149 W. Nielsen Avenue, Suite 102, Fresno, CA 93706, Fresno County
Full Name of Registrant Mercantile Distributing Inc. 1149 W. Nielsen Avenue,
Suite 102, Fresno, CA 93706 Registrant commenced to transact business under the Fictitious Business Name listed above on January 1,
2018.
This business conducted by: Corporation
Articles of Incorporation C4075005
Type or Print Signature and Title
Steven Anthony Matthews,