Page 18 - Mid Valley Times 3-5-20 E-edition

B6
B5
Mid Valley Times Thursday March 5, 2020
PUBLIC NOTICES
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT
District Of ce
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Uni ed School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening
March 16, 2020, at 10:00 a.m. at the Educa- tional Support Center, 1801 10th St, Reedley CA 93654. Bidders not attending one of the pre-bid conference will be disquali ed.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certi ed check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to sub- stitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in ac- cordance with the California Public Contract Code, providing for the licensing of contrac- tors. In accordance with Section 3300 of said Code, the bidder shall have a Class “B” license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty- ve Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid.
The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevail- ing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classi ed in an amount not less than the rates speci ed. Copies of the required rates are on le at the Owner’s business of ce and are available on request.
John G. Campbell, Superintendent
March 5, 12, 2020
for the award of the Contract to construct:
Bid No. 1910 Riverview & Washington School Modular Installation & Site Work as per drawings and speci cations which may now be obtained electronically from the Archi-
tect: Hastrup & Hyde, Inc. 420 Clovis Avenue, Suite A
Clovis, CA 93612
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequali cation pursuant to Public
Contract Code section 20111.6.
Public works projects shall be subject to com- pliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be quali ed to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and quali ed under Labor Code section 1725.5 to perform public work as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be quali ed to enter into, or engage in the performance of, any contract of public work (as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and quali ed under Labor Code section 1725.5 to perform public work. Contract Time shall be from April 15, 2020 to July 1, 2020 (78) calendar days, and liquidat- ed damages for delay shall accrue.
Bids must be sealed and led at the Educa- tional Support Center at 1801 10th St, Reed- ley, CA 93654 by March 25, 2020, before 2:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted. Mandatory pre-bid conference will be held on
CITY COUNCIL CITY OF PARLIER STATE OF CALIFORNIA
and will not be discriminated against on the grounds of race, color, religious creed, sex, or national origin in con- sideration for an award.
Bidders are advised that, as required by federal law, the City of Parlier is implementing Disadvantaged Business Enterprise (DBE) requirements for this project. These re- quirements are addressed in the Special Provisions. The DBE Contract goal for this project is 15.0 percent
This project is subject to the “Buy America” provisions of the Surface Transportation Assistance Act of 1982 as Amended by the Intermodal Surface Transportation Ef - ciency Act of 1991.
In accordance with the provisions of Labor Code Sec- tion 1771, this Project is subject to the general prevailing rates and wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Labor Code Section 1773.8. Said wage determinations are on le with the City Clerk, City of Parlier, 1100 E. Parlier Avenue, Parlier, California, or on the State of California Department of Industrial Relations website at www.dir.ca.gov/dirdatabases.html, and are in- corporated herein by reference.
Federal minimum wage rates, as predetermined by the U.S. Department of Labor, are available on the following website: www.wdol.gov/dba.aspx. If there is a difference between the federal minimum wage rates predetermined by the U.S. Department of Labor and the Prevailing Wage Rates determined by the Director of the Department of Industrial Relations of the State of California for similar classi cations of labor, the Contractor and his subcontrac- tor shall pay no less than the higher wage rate.
No contractor or subcontractor may be listed on a bid proposal for a public works project (submitted on or af- ter March 1, 2015) unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5[with limited exceptions from this requirement for bid purposes only under Labor Code section 1771.1(a)]. No contractor or subcontractor may be awarded a con- tract for public work on a public works project (awarded on or after April 1, 2015) unless registered with the De- partment of Industrial Relations pursuant to Labor Code section 1725.5.
This project is subject to compliance monitoring and en- forcement by the Department of Industrial Relations. Bids are required for the entire work described herein. Bids will be compared on the basis of the total bid items. The City Council reserves the right to reject any or all bids, to waive any informality in the bids received, or to award the contract to the lowest responsible bidder as may serve the best interests of the City of Parlier.
March 5, 12, 2020
NOTICE TO CONTRACTORS
Sealed proposals will be received at the of ce of the City Clerk, 1100 E. Parlier Avenue, Parlier, California 93648, until 2:00 p.m., Wednesday, April 1st, at which time they will be publicly opened and read in said building for con- struction in accordance with the speci cations therefore, to which special reference is made as follows:
MERCED – TUOLOMNE ALLEY PAVEMENT
K STREET TO ZEDIKER AVENUE FEDERAL PROJECT NO. CML-5252(025)
Plans and speci cations applying to this project may be obtained at the of ce of Philip Romero, the City Engineer, Yamabe & Horn Engineering, Inc., 2985 N. Burl Avenue, Suite 101, Fresno, CA 93727 at the non-refundable price of $25 per set. If mailed there will be a non-refundable
charge of $30 per set.
Plans and speci cations can be examined at the of ce of the Director of Public Works at 1100 E. Parlier Avenue, Parlier, California 93648.
No bidder may withdraw his/her bid within 30 days after the actual date of the opening thereof.
Planholder names may be obtained only from the City Engineer, beginning six working days prior to the date of bid opening.
Inquiries regarding this project should be directed to the City Engineer, Philip Romero, (559) 244-3123.
Bids shall be submitted in a sealed envelope addressed to the City Clerk labeled with the name of the bidder, the name of the project and the statement “DO NOT OPEN UNTIL THE TIME OF BID OPENING”.
No bid will be considered unless it is made on proposal form furnished by the City Engineer. Each bid must be accompanied by a certi ed or cashier’s check or bidder’s bond, made payable to the City of Parlier, for an amount equal to at least ten percent (10%) of the amount bid. A Performance Bond in the amount equal to one hundred percent (100%) of the contract amount and a Labor and Materials Bond in the amount equal to one hundred per- cent (100%) of the contract amount will be required by the City from the bidder to whom the contract is awarded within ten (10) days after notice of award of the contract. No contract will be awarded to a Contractor who has not been licensed in accordance with the provisions in Public Contract Code Section 3300, as amended, or whose bid is not on the proposal form included in the contract docu- ments. A valid California Class ‘A’ Contractor’s License is required for this project.
The City of Parlier hereby noti es all bidders that it will af rmatively ensure that in any contract entered into pur- suant to this advertisement, Disadvantaged Business Enterprise (DBE), Minority Business Enterprise, and Women-Owned Business Enterprise will be afforded full opportunity to submit bids in response to this invitation
NOTICE TO BIDDERS
Notice is hereby given that Sanger Uni ed School District (hereinaf- ter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the Contract to
bond from a surety insurer satisfactory to the Owner.
Bids must be accompanied by an executed Fingerprinting Notice and Acknowledgment.
Pursuant to the Contract Documents, the successful bidder will be re- quired to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, said bonds to be secured from Admitted Surety insurers (an insurance organization authorized by the Insurance Com- missioner to transact business of insurance in the State of California during this calendar year). The surety insurers must, unless otherwise agreed to by Owner in writing, at the time of issuance of the bonds, have a rating not lower than “A-” as rated by A.M. Best Company, Inc. or other independent rating companies. Owner reserves the right to approve or reject the surety insurers selected by the successful bidder and to require the successful bidder to obtain bonds from surety insur- ers satisfactory to the Owner. The bidder will be required to furnish insurance as set forth in the Contract Documents.
The successful bidder will be allowed to substitute securities or estab- lish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a Class “B” license and shall maintain that license in good standing through Completion of the Contract and all applicable war- ranty periods. Bidder shall state the California contractor license num- ber, and for all projects over Twenty- ve Thousand Dollars ($25,000) the public works contractor registration number, on the Designation of Subcontractors form for all subcontractors doing more than one-half of one percent (0.5%) of the bidder’s total bid. An inadvertent error in listing a California contractor’s license number shall not be grounds for ling a bid protest or for considering the bid nonresponsive if the bid- der submits the corrected contractor’s license number to the Owner within 24 hours after the bid opening, or any continuation thereof, so long as the corrected contractor’s license number corresponds to the submitted name and location for that subcontractor.
Subcontractors shall maintain their licenses in good standing through Completion of the Contract and all applicable warranty periods. Own- er reserves the right to reject any bid as nonresponsive if bidder or any subcontractor is not licensed in good standing from the time the bid is submitted to Owner up to award of the Contract, whether or not the bidder listed the subcontractor inadvertently, or if a listed subcontrac- tor’s license is suspended or expires prior to award of the Contract. Owner also reserves the right to reject any bid as non responsive if a listed subcontractor’s license is not in good standing to perform the work for which it is listed from the time of submission of the bidder’s bid to award of the Contract.
The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classi ed in an amount not less than the rates speci ed. Copies of the required rates are on le at the Owner’s business of ce and are available to any interested party on request.
The Owner reserves the right to waive any irregularity and to reject any or all bids.
Unless otherwise required by law, no bidder may withdraw its bid for a period of sixty (60) days after the date set for the opening thereof or any authorized postponement thereof. The Owner reserves the right to take more than sixty (60) days to make a decision regarding the rejection of bids or the award of the Contract.
March 5, 12, 2020
construct: PROJECT NO. 1000-20-006 SITE IMPROVEMENTS AT
WILSON ELEMENTARY SCHOOL
610 FALLER AVE
SANGER, CA 93657
as per drawings and speci cations which may now be obtained from
the Architect MANGINI ASSOCIATES, INC. 4320 WEST MINERAL KING AVE
VISALIA, CA 93291
(559) 627-0530
upon deposit of Two-Hundred Dollars ($200.00) refundable when drawings and speci cations are returned in good condition as indi-
cated in the “Instruction to Bidders.”
The lowest bid shall be determined on the amount of the base bid. The Owner reserves the right to add or deduct any of the additive or deductive alternate items after the lowest responsible and responsive bidder is determined.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. For all proj- ects over Twenty- ve Thousand Dollars ($25,000), a contractor or subcontractor shall not be quali ed to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code sec- tion 4104 unless currently registered and quali ed under Labor Code section 1725.5 to perform public work as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty- ve Thousand Dollars ($25,000), a contractor or subcontrac- tor shall not be quali ed to enter into, or engage in the performance of, any contract of public work (as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and quali ed under Labor Code section 1725.5 to perform public work. Time is of the essence in this Contract, and the time of Completion for the Work (“the Contract Time”) shall be Sixty (60) calendar days from the date of commencement of the Work as established in the Owner’s Notice to Proceed.
Bids will be sealed and led in the Business Of ce of the Owner at:
Sanger Uni ed School District
DISTRICT OFFICE
1905 7th Street
SANGER, CALIFORNIA 93657
On April 2, 2020, before 3:00 p.m. on the clock designated by the Owner or its representative as the bid clock. Facsimile (FAX) and
Electronic (EMAIL) copies of the bid will not be accepted.
Bids will be opened on April 2, 2020, at 3:00 p.m. as calculated by the clock designated by the Owner or its representative as the bid clock. A Mandatory Pre-bid conference will be held on March 18, 2020, at 2:00 p.m. at Wilson Elementary, 610 Faller Ave, Sanger CA 93657. Bidders not attending the conference will be disquali ed.
The Owner will require the successful Bidder to achieve the minimum goal of 3% DVBE (Disabled Veteran Business Enterprises) estab- lished in the bidding documents or to provide acceptable evidence of good faith efforts to do so. The DVBE documents must be sealed and led in the Business Of ce of the Owner at the same time the bid is sealed and led.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certi ed check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner. If a bid bond is used, it must be issued by an Admitted Surety (an insurance organization authorized by the Insurance Commissioner to transact surety insurance in the State of California during this calendar year), which shall be given as a guarantee that the bidder will enter into a Contract if awarded the Work and will be declared forfeited, paid to, or retained by the Owner as liquidated damages if the bidder refuses or neglects to enter into the Contract provided by the Owner after being requested to do so. The surety insurer must, unless otherwise agreed to by Owner in writ- ing, at the time of issuance of the bond, have a rating not lower than “A-” as rated by A.M. Best Company, Inc. or other independent rating companies. Owner reserves the right to approve or reject the surety insurer selected by Contractor and to require Contractor to obtain a
KINGS CANYON UNIFIED SCHOOL DISTRICT
NOTICE TO BIDDER
The Board of Trustees of the Kings Canyon Uni ed School District of Fresno County, California invites quali ed dealers and will receive sealed proposals for BID NO. 1911 District Fleet Dump Truck Re- placement on or before 2:00 PM, on March 20, 2020 at the Pur- chasing Department located at 1502 I Street Reedley, California 93654, after which time and place the bids will be opened and read in public. Proposals must be submitted in a sealed envelope, marked with the bid number and title. The selected dealer will be responsible for meeting or exceeding all vehicle speci cations listed in this Re-
quest for Proposal (RFP).
Bidders may not withdraw bids for a period of forty- ve (45) days after the date set for opening of bids.
Bids shall be made on forms prepared by the Kings Canyon Uni ed School District. Bid forms, speci cations and further information may be obtained from Monica Sanchez, Purchasing Manager by phone (559) 305-7037.
Proposals received later than the designated time and speci ed will be returned to the bidder unopened. Facsimile or email submittals of the proposal will not be accepted. The District reserves the right to request additional information or clari cation if needed, upon review of your Proposal. This Request for Proposal should not be construed as a guarantee of business or contract.
The District reserves the right to accept or reject any or all proposals, or any combination of proposals and to waive any irregularities or informalities which may be legally waived.
John G. Campbell, Superintendent
March 5, 12, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF Julio Campos CASE NO. 20CEPR00176 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both,
of: Julio Campos
A Petition for Probate has been filed by: Maria E Campos in the Superior Court of California, County of Fresno.
The Petition for probate
requests that Maria E Campo be appointed as personal representative to administer the estate of the decedent.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very
important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition
will be held in this court as follows:
Date: April 2, 2020
Time: 9:00 am
Dept.: 303
Address of court: 1130 "O" Street, Fresno, California 93721 B. F. Sisk Courthouse If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in
person or by your attorney.
If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the
date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the
court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Petitioner: Maria E Campos 622 N Haney Ave
Reedley, CA 93654 559-643-6119
March 5, 12, 19, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010000587 The following person(s) is(are) conducting business
as:
Kari's Field Services, 5741 N Cleo Ave, Fresno, CA 93722 County of FRESNO Registrant:
Kari Samulka, 5741 N Cleo Ave, Fresno, CA 93722 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A.
This business is conducted by: an Individual
This Statement has been executed pursuant to section 17919 of the Business and Professions code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1000.) S/Kari Samulka,
Filed with the Fresno County Clerk on 01/28/2020.
A New Fictitious Business
Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
2/13, 2/20, 2/27, 3/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010000650 The following person(s) is(are) conducting business
as:
Ron Forbes Inspection Services, 1572 Magnolia Ave., Clovis, CA 93611, County of Fresno Registrant:
Ronald William Forbes, 1572 Magnolia Ave., Clovis, CA 93611
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: individual
Articles of Incorporation: This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Ronald William Forbes, Owner
Filed with the Fresno County Clerk on January 31, 2020 A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New filing
2/13, 2/20, 2/27, 3/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010000769 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Travelus
4781 E Gettysburg Ave, Suite 116, Fresno, CA 93726 Fresno County (559) 293-4788
Mailing Address
4781 E Gettysburg Ave, Suite 116, Fresno, CA 93726
Full Name of Registrant
Travelus Holdings, Inc. 6080 Center Drive #603, Los Angeles, CA 90045 Registrant commenced to transact business under the Fictitious Business Name listed above on February 5,
2020.
This business conducted by: Corporation
Articles of Incorporation C4253590
Type or Print Signature and