Page 14 - Mid Valley Times 10-8-20 E-dition

Thursday, October 8, 2020 | B4 | Mid Valley TiMes PUBLIC NOTICES
NOTICE TO BIDDERS
Notice is hereby given that sealed bids will be received by the City Council of the City of Reedley for furnishing all labor, materials, services, and equipment and performing all work necessary for the ROADWAY SAFETY SIGNING AUDIT, Project No. HSIPL-5216(052) in the City of Reed- ley, Fresno County.
Project plans, special provisions, bid and contract docu- ments are on le and may be examined at the City’s web- site www.reedley.ca.gov and at the Of ce of the City Engi- neer, 1733 Ninth Street, Reedley, California, 93654, (559) 637-4200, ext. 295. Copies may also be examined at the following Builders Exchanges:
•Central California Builders Exchange •Tulare-Kings Builders Exchange •McGraw-Hill Construction Dodge •Construction Bid Board
Plans and speci cations may be obtained at the City of Reedley for a charge of FIFTY-FIVE dollars ($55.00) per set, nonrefundable. In addition, there will be a twelve dollar ($12.00) mailing and handling charge for any sets mailed. Electronic copies can be obtained for a charge of ten dollar ($10.00), nonrefundable. Only those who have purchased plans and speci cation from the of ce of the City Engineer will be considered eligible prime bidders. Description of Work: The work includes, in general, in- stalling and/or upgrading signage, striping and pavement markings.
This work shall be diligently prosecuted to completion before the expiration of THIRTY (30) CONSECUTIVE WORKING DAYS beginning on the day speci ed in the Notice to Proceed.
The City of Reedley hereby noti es all bidders that it will af rmatively insure that in any contract entered into pursu- ant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religious creed, sex, or national origin in consideration for an award.
The DBE contract goal is 9 percent.
The prevailing wage rates as determined by the Director of Industrial Relations of the State of California shall ap- ply to this project. In accordance with the provisions of Section 1770 of the Labor Code, the Director of the De- partment of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vaca- tion, travel time, and subsistence pay as provided for Sec- tion 1773.8 of the California Labor Code, apprenticeship or other training programs authorized by Section 3093 of said code, and similar purposes applicable to the work to be done. Said wages are on le with the City of Reedley and County of Fresno and are incorporated herein as part of the special provisions. By submission of a bid, bid- der stipulates and agrees to abide by the provisions of the Labor Code related to payment of prevailing wage or promptly pay a penalty of $50.00 per day per worker paid less than prevailing wage pursuant to the provisions of La- bor Code Section 1775. A work day shall not exceed eight hours labor per day or forty (40) hours labor per week. The successful bidder shall keep an accurate record of employees’ hours worked by calendar day and week. Minimum wage rates for this project, as predetermined by the Secretary of Labor, are set forth herein in the bid and contract documents and incorporated as part of the spe- cial provisions. These wage rates may be examined at the City of Reedley where the project plans, special provi- sions, bid and contract documents may be seen. If there is a difference between the minimum wage rates predeter- mined by the Secretary of Labor and the prevailing wage
rates determined by the Director of the Department of In- dustrial Relations of the State of California for similar clas- si cations of labor, the Contractor and his subcontractors shall pay not less than the higher wage rate.
Bids must be led with the Reedley City Engineer, 1733 Ninth Street, Reedley, not later than 3:00 p.m., Thursday, October 29, 2020, at which time the Of ce of the City Engineer of the City of Reedley will open said bids. Bids must be submitted in a sealed envelope and marked on the outside of the envelope “ROADWAY SAFETY SIGNING AUDIT” together with the name and address of the bidder. The bids will be opened and read publicly at that time.
Each bid must be accompanied by either a cashier’s check, certi ed check or bidder’s bond in a sum equal to at least ten (10%) percent of the total amount bid. Checks or bonds must be made payable to the City of Reedley; such securities shall be a guarantee that the bidder, if his bid is accepted, will enter into a satisfactory contract and furnish a good and suf cient bond for faithful performance thereof and for payment of labor and material costs in ac- cordance with the requirements of the plans and speci - cations.
No contract will be awarded to a Contractor who has not been licensed in accordance with the provisions of Chap- ter 791, Statutes of 1929, as amended, or whose bid is not on the proposal form included in the contract documents. An appropriate and valid California Contractor’s License is required for the project. Class A General Engineering Contractors license is required.
No contractor or subcontractor may be listed on a bid proposal for a public works project (submitted on or af- ter March 1, 2015) unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5 [with limited exceptions from this requirement for bid purposes only under Labor Code section 1771.1(a)]. No Contractor or subcontractor may be awarded a con- tract for public work on a public works project (awarded on or after April 1, 2015) unless registered with the De- partment of Industrial Relations pursuant to Labor Code section 1725.5.
This project is subject to compliance monitoring and en- forcement by the Department of Industrial Relations. Interpretations: All questions about the meaning or intent of the Contract Documents shall be directed to the of ce of the City Engineer in writing. Interpretations or clari - cations considered necessary by the City Engineer in re- sponse to such questions will be resolved by the issuance of addenda delivered to all parties listed on the plan hold- ers list. Questions received less than 3 business days prior to the date of opening bids shall be considered non- responsive and therefore not addressed. Only questions that have been resolved by formal written addenda shall be binding. Oral and other interpretations or clari cations will be without legal or contractual effect.
The City reserves the right to reject any or all bids, to waive any informality in bids received, or to award the contract to the lowest responsible bidder complying with these instructions as may serve the best interest of the City of Reedley. The City reserves the right to award the contract to other than the lowest bidder if it appears that the best interests of the City of Reedley will be served thereby.
BY THE ORDER OF THE CITY COUNCIL OF THE CITY
OF REEDLEY
October 8, 2020
NOTICE OF INTENT TO APPOINT GOVERNING BOARD MEMBER
KINGS RIVER UNION SCHOOL DISTRICT
BE IT KNOWN THAT the Kings River Union School District had an insuf cient number of candidates le for the position of governing board member in Trustee Area 5 for the election to be held on No- vember 3, 2020. No persons have been nominated for one (1) gov- erning board member vacancy in Trustee Area 5 with a four-year term to expire on December 13, 2024.
In accordance with Education Code Section 5328, the governing board of the Kings River Union School District shall, at a meeting held prior to November 3, 2020, appoint one member in Trustee Area 5 for a term of four years.
Interested quali ed residents of the district are invited to make ap- plication at the school district of ce located at: 3961 Avenue 400, Kingsburg.
Dated: September 14, 2020By ___________________________ Clerk, Kings River Union School District October 1, 8, 2020
CITY OF SANGER
SUMMARY OF ORDINANCE NO. 2020-06
NOTICE IS HEREBY GIVEN that on October 1, 2020, the Sanger
City Council approved the following ordinance:
Ordinance No. 2020-06, an Ordinance of the City Council of the City of Sanger amending Division 2 “Purchasing” of Chapter 2, Article V, by Adding Section 2-222 of the Sanger City Code Relat- ing to Design-Build Projects.
A copy of Ordinance No. 2020-06 is available at the City Clerk’s of ce at City Hall, 1700 7th Street, Sanger, CA 93657.
/s/ Rebeca Padron City Clerk
October 8, 2020
ADVERTISEMENT OF SALE NOTICE IS HEREBY GIVEN that the undersigned intends to sell the personal property described below pursuant to section 21702 of the Government Code. The undersigned will sell at public sale by competitive bidding on the 16th of October on the premises where said property has been stored and which are located at: Lock & Leave Self Storage, 1366 North Crawford Ave. Dinuba CA 93618. County of Tulare; State of California, sale
begins at 9:30 AM Agustine Calvillo
Dan or Joy Johnston Laura Padron
Thatcher Wong
Vanessa M. Gonzalez PROPERTY TO BE SOLD DESCRIBED AS: BICYCLE, SHOES, MOP BUCKET, CABINETS, YARD TOOLS, BOOTS, DRESSER, CLOTHING, TOTES (CONTENTS UNKNOWN), ROTO TILLER, STUFFED ANIMALS, SHELVING, GOLF CLUBS, PALLETS, BOXES (CONTENTS UNKNOWN), BAGS (CONTENTS UNKNOWN), TRASH, MISCELLANEOUS HOUSEHOLD ITEMS, TOOL BOXES, WICKER FURNITURE, BLOWER, GLIDER, CHAIRS, ELECTRIC EQUIPMENT Purchases must be paid for in cash at the time of the auction. All purchased items are sold as is, where is, and must be removed at the time of sale. Sale is subject to cancellation in the event of settlement between owner and obligated party. This auction held with "reserve" dated this 16th of October.
A-Ward Auction
9411 Vintner Circle Diablo Grande, CA 95207 Joe Ward
Bond# MS237-04-79
Jeff Vercelli
Bond# MS153-13-71
October 1, 8, 2020
ORDER TO OF Karen Emily Basmajian FOR CHANGE OF NAME CASE NUMBER:
20 CE CG 02000
TO ALL INTERESTED PERSONS:
Petitioner: Karen Emily
Basmajian filed a petition with this court for a decree changing name as follows: Present Name
Karen Emily Basmajian Proposed Name
Karina Emily Basmajian THE COURT ORDERS that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.
NOTICE OF HEARING
a. Date: October 26, 2020 Time: 8:30 AM Dept.:404 b. The address of the court Civil Division
1130 O Street
Fresno CA 93724
A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this count: Mid Valley Times/ Reedley Exponent P.O. Box 432, Reedley, CA 93654 (559) 638-2244
Date: July 13, 2020 Signed /s/ Mark E. Cullers Judge of the Superior Court
September 17, 24, October 1, 8, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF Esther O. Fernandez CASE NO. 20CEPR00571 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: Esther O. Fernandez, Ester Ontiveros, Esther Ontiveros
Fernandez
A Petition for Probate has been filed by: Gilbert M. Fernandez in the Superior Court of California, County of Fresno.
The Petition for probate
requests that Gilbert M. Fernandez be appointed as personal representative to administer the estate of the decedent.
The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: October 29, 2020 Time: 9:00 am
Dept.: 303
Address of court: 1130 "O" Street, Fresno, California 93721 B. F. Sisk Courthouse
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority
may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Petitioner: Gilbert M. Fernandez
271 Brehler Ave
Sanger, CA 93657 559-349-3263
September 24, October 1, 8, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF JOHN LEE TARBELL, aka JOHN L. TARBELL, and JOHN TARBELL
CASE NO. VPR050196 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: JOHN LEE TARBELL, aka JOHN L. TARBELL, and JOHN
TARBELL
A Petition for Probate has been filed by: CLAUDIA DENICE HERNANDEZ in the Superior Court of California, County of TULARE.
The Petition for probate requests that CLAUDIA DENICE HERNANDEZ be appointed as personal representative to administer the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person
files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: November 2, 2020 Time: 10:00 A.M.
Dept.: 7
Address of court: 221 South Mooney Blvd, Visalia, CA 93291 Probate
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for petitioner: Gerald M. Tomassian 3419 W. Shaw Avenue Fresno, CA 93711
(559) 277-7300
October 1, 8, 15, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004074 The following person(s) is(are) conducting business
as:
Universal Service Agency, 595 East Swedesford Road, Suite 350, Wayne, PA 19087, County of Chester
Registrant:
R&P Surety, LLC, 595 East Swedesford Road, Suite 350, Wayne, PA 19087 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: n/a
This business is conducted by: Limited Liability Company
Articles of Incorporation: 202022310052
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Matthew J. Rosenberg, Manager
Filed with the Fresno County Clerk on August 28, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
9/17, 9/24, 10/1, 10/8/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004087 The following person(s) is(are) conducting business
as:
Creative, 2071 W Warner, Fresno, CA 93711, County of Fresno
Registrant:
Joseph Luprete, 2071 W Warner, Fresno, CA 93711 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: n/a
This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Joseph Luprete, Owner Filed with the Fresno County Clerk on August 31, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
9/17, 9/24, 10/1, 10/8/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004270 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Fresno Paper Express 2822 S. Maple Ave, Fresno, CA 93725 Fresno County
Mailing Address
2822 S. Maple Ave, Fresno, CA 93725
Full Name of Registrant
Paper, Pulp & Film Inc 2822 S. Maple Ave, Fresno, CA 93725 Registrant commenced to transact business under the Fictitious Business Name listed above on January 1,
2000.
This business conducted by: Corporation
Articles of Incorporation C1650110
Registrant’s Name and Title Talleyrand Leroy Cloud Filed with the Fresno County Clerk on: September 8, 2020
A new statement must be filed prior to the expiration date.
Notice: this statement expires on September 7, 2025
Brandi L. Orth, County Clerk
By: Yvette Jamison, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004269 The Following Persons are Conducting Business as
New Filing
Fictitious Business Name:
T.L.C.
2822 S. Maple Ave, Fresno, CA 93725 Fresno County
Mailing Address
2822 S. Maple Ave, Fresno, CA 93725
Full Name of Registrant
Talleyrand Leroy Cloud 2822 S. Maple Ave, Fresno, CA 93725
G. Carol Cloud
323 Carolina, Clovis, CA 93611 Meredith Ormen 13723 Killarny Drive, Madera, CA 93636 Registrant commenced to transact business under the Fictitious Business Name listed above on June 22,
1994.
This business conducted by: General Partnership Registrant’s Name and Title Talleyrand Leroy Cloud Filed with the Fresno County Clerk on: September 8, 2020
A new statement must be filed prior to the expiration date.
Notice: this statement expires on September 7, 2025
Brandi L. Orth, County Clerk
By: Yvette Jamison, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS
NAME STATEMENT File No. 2202010004170 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Rush Safety Consulting 2019 Whiteash Ave., Clovis, CA 93619 Fresno County (559)307-4267
Full Name of Registrant
Kimberly Rush 2019 Whiteash Ave., Clovis, CA 93619 This business conducted
by: An Individual Registrant commenced to transact business under the Fictitious Business Name listed above on N/A Registrant’s Name Kimberly Rush, Officer’s Title Owner Filed with the Fresno County Clerk on: September 2, 2020 Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003986 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Two Saddles 6604 N Marty Ave, Fresno, CA 93711 Fresno County 559-916-0234
Mailing Address
1516 Sylvan Way Apt. 210,
Lodi, CA 95242 San Joaquin County
Full Name of Registrant
Emily Wilkins
1516 Sylvan Way Apt. 210,
Lodi, CA 95242
This business conducted
by: An Individual Registrant commenced to transact business under the Fictitious Business Name listed above on Registrant’s Name Emily Wilkins, Officer’s Title Owner
Filed with the Fresno County Clerk on: August 25, 2020
Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004102 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Victor Echeverria- Goosehead Insurance Agency
1626 7th St #112, Sanger, CA 93657 Fresno County (559) 728-4850
Mailing Address
PO Box 658 Sanger, CA 93657
Full Name of Registrant
Deo Speravi Inc.
1626 7th St #112, Sanger, CA 93657 This business conducted
by: A Corporation
Articles of Incorporation
4583155
Registrant commenced to transact business under the Fictitious Business Name listed above on Registrant’s Name Victor R. Echeverria Jr, Officer’s Title President
Filed with the Fresno County Clerk on: August 31, 2020
Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003905 The Following Persons are Conducting Business as
New Filing
Fictitious Business Name: Legacy Investment Group
5090 N. Primitivo Way Apt 301, Fresno, CA 93710 Fresno County (559) 304-7115
Full Name of Registrant
Nathan Eddins 5090 N. Primitivo Way Apt 301,
Fresno, CA 93710 Franklin Delos Santos 6395 e inyo st fresno, ca 93727 This business conducted
by: A General Partnership Registrant commenced to transact business under the Fictitious Business Name listed above on N/A Registrant’s Name Nathan Eddins Officer’s Title general partner
Filed with the Fresno County Clerk on: August 20, 2020
Brandi L. Orth, County Clerk
By: Dakota Thurston, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004220 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Lovely Lynn’s 246 W Strother Fresno, CA 93706 Fresno County
Full Name of Registrant
Courtney Bess
246 W Strother Fresno, CA 93706 This business conducted
by: An Individual Registrant commenced to transact business under the Fictitious Business Name listed above on Registrant’s Name Courtney Bess, Registrant’s Title
Filed with the Fresno County Clerk on: September 4, 2020 Brandi L. Orth, County Clerk
By: Cyan Edmisten, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003985 The Following Persons are Conducting Business as
New Filing
Fictitious Business Name:
A&J Farm Services
664 W Mariposa St, Kingsburg, CA 93631 Fresno County
Full Name of Registrant
Alejandra Rios Ontiveros 664 W Mariposa St, Kingsburg, CA 93631 Tomas A Beltran Beltran Jr
420 Dover Street Delano, CA 93215 This business conducted
by: Joint Venture Registrant commenced to transact business under the Fictitious Business Name listed above on N/A Registrant’s Name Alejandra Rios Ontiveros Officer’s Title General Partner
Filed with the Fresno County Clerk on: August 25, 2020
Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004126 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Little Sweet Babes 2274 S. Preuss Ave Fresno, CA 93727