Page 15 - Mid Valley Times 7-14-22 E-Edition

ant to Labor Code Sec. 1725.5. This project is subject to compliance monitor- ing and enforcement by the Department of Industrial Relations. This contract is subject to state contract nondiscrimination and compliance require- ments pursuant to Gov- ernment Code, Section 12990.
A contractor or sub- contractor shall not be qualified to bid on, be listed in a bid proposal, subject to the require- ments of Section 4104 of the Public Contract Code, or engage in
the performance of
any contract for public work, as defined in
this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this sec- tion for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Profes- sions Code or by Sec- tion 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded. Inquiries or questions based on alleged pat- ent ambiguity of the plans, specifications
or estimate must be communicated as a bidder inquiry prior to bid opening. Any such inquiries or questions, submitted after bid opening, will not be treated as a bid protest. Technical questions should be directed to Javier Andrade, PE, telephone (559) 429- 4747.
Printed plans, specifica- tions and bid docu- ments may be obtained for a NONREFUND- ABLE FEE OF $ 60.00 per set from:
A&M Consulting Engi- neers220 North Locust Street, Visalia, CA(559) 429-4747
An additional charge of $25.00 per set will be made for mailing. Pursuant to Section 1773 of the Labor Code, the general prevailing wage rates in the county, or counties, in which the work is
to be done have been determined by the Di- rector of the California Department of Indus- trial Relations. These wages are set forth in the General Prevailing Wage Rates for this project, available at City of Parlier City Hall, 1100 E Parlier Ave, Parlier, California, and available from the California Department of Industrial Relations’ Internet web site at http://www.dir. ca.gov. The Federal minimum wage rates
for this project as predetermined by the United States Secretary of Labor are set forth
in the books issued for bidding purposes en- titled “Bid Book,” and in copies of this book that may be examined at the offices described above where project plans, special provisions, and proposal forms may
be seen. Addenda
to modify the Federal minimum wage rates,
if necessary, will be is- sued to holders of “Bid Books.” Future effec- tive general prevailing wage rates, which have been predetermined and are on file with the California Department of Industrial Relations are referenced but not printed in the general prevailing wage rates. Attention is directed to the Federal minimum wage rate requirements in the books entitled “Bid Book.” If there is a difference between the minimum wage rates predetermined by the Secretary of Labor and the general prevailing wage rates determined by the Director of the California Department of Industrial Relations for similar classifica- tions of labor, the Con- tractor and subcontrac- tors shall pay not less than the higher wage rate. The Department will not accept lower State wage rates not specifically included in the Federal minimum wage determinations. This includes “helper”
(or other classifica- tions based on hours
of experience) or any other classification
not appearing in the Federal wage determi- nations. Where Federal wage determinations
do not contain the State wage rate determina- tion otherwise available for use by the Contrac- tor and subcontractors, the Contractor and subcontractors shall pay not less than the Federal minimum wage rate that most closely approximates the duties of the employees in question.
The U.S. Department of Transportation (DOT) provides a toll-free hotline to report bid rigging activities. Use the hotline to report
bid rigging, bidder collusion, and other fraudulent activities. The hotline number is (800) 424-9071. The service is available 24 hours 7 days a week and is confidential and anonymous. The hotline is part of the DOT’s effort to identify and investigate highway construction contract fraud and abuse and
is operated under the direction of the DOT Inspector General. July 14, 2022
NOTICE INVITING BIDS
Sealed bids shall be hand delivered or mailed to: Kings Can- yon Unified School Dis- trict, Attn: Educational Support Center, located at 1801 10th Street, Reedley, CA 93564 and will be accepted until 11:00 AM on August 10th, 2022, at which time or thereafter said bids will be opened and read aloud for perform- ing the work as follows:
DUNLAP LEADER- SHIP ACADEMY WATER SUPPLY UPGRADE AND CONSOLIDATION PROJECT
The project area is located in Dunlap, CA, at 39667 Dunlap Road. The project includes installation of 3,020 LF of buried 4-inch drinking waterline and 890 LF
of 6-inch irrigation wa- terline by open trench construction, installation of a new 25,000 gallon bolted steel water stor- age tank, installation of new 10,000 gallon and 7,000 gallon HDPE wa- ter storage tanks, well site pump station and blending station in a 16-ft x 20-ft building, (2) booster pump stations in 8-ft x 12-ft buildings, a new 5,000 gallon hydropneumatic tank, (2) 2,000 gallon hydro- pneumatic tanks, and installation of power, control instrumentation and lighting complete and operational. Con- struction shall include all other facilities and equipment, and all management, super- intendence, permits, labor and services in accordance with the Contract Documents therefore adopted and on file with the District to complete this project. Water service in the existing system shall
be maintained during construction. Bids shall be valid for 90 calendar days after the bid open- ing date.
A mandatory pre-bid conference and site- walk will start at the Dunlap Elementary School parking lot at 39667 Dunlap Road at 11:00 AM on July 27th, 2022, To confirm atten- dance, email rj.jol2@ gmail.com or text (209) 629-9220.
Bidders may obtain
a copy of the Con-
tract Documents from the Public Purchase website at: https://www. publicpurchase.com/ gems/kcusd,ca/buyer/ public/home.
It is the responsibility of the Contractor to check the website for any ad- dendums to the project. Bids must be ac- companied by cash, a certified or cashier’s check, or a Bid Bond
in favor of District in an amount not less than ten percent (10%) of the submitted Total Bid Price.
Each bid shall be accompanied by the se- curity referred to in the Contract Documents, the non-collusion affida-
vit, the list of proposed subcontractors, and all additional documenta- tion required by the Instructions to Bidders. The successful bidder will be required to furnish District with
a Performance Bond equal to 100% of the successful bid, and a Payment Bond equal to 100% of the successful bid, prior to execution of the Contract. All bonds are to be secured from a surety that meets all of the State of Califor- nia bonding require- ments, as defined in Code of Civil Procedure Section 995.120, and is admitted by the State of California.
Pursuant to Public Contract Code Section 22300, the successful bidder may substitute certain securities for funds withheld by District to ensure his performance under the Contract.
The Director of In- dustrial Relations has determined the general prevailing rate of per diem wages in the locality in which this work is to be performed for each craft or type
of worker needed to execute the Contract which will be awarded to the successful bid- der, copies of which
are on file and will be made available to any interested party online at http://www.dir.ca.gov/ dlsr. A copy of these rates shall be posted by the successful bidder
at the job site. The successful bidder, and all subcontractor(s) under him, shall comply with all applicable Labor Code provisions, which include, but are not limited to the payment of not less than the re- quired prevailing rates to all workers employed by them in the execu- tion of the Contract,
the employment of apprentices, the hours of labor and the debar- ment of contractors and subcontractors.
A contractor or sub- contractor shall not be qualified to bid on, be listed in a bid proposal, subject to the require- ments of Section 4104 of the Public Contract Code, or engage in
the performance of
any contract for public work, as defined in
this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this sec- tion for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Profes- sions Code or by Sec- tion 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded. Each bidder shall be a licensed contractor pur- suant to the Business and Professions Code and shall be licensed in the following appropri- ate classification(s) of contractor’s license(s), for the work bid upon, and must maintain the license(s) throughout the duration of the Contract: GENERAL ENGINEERING CON- TRACTOR CLASS A LICENSE.
Funding for this project has been provided in full or in part under the Safe and Affordable Drinking Water Fund through an agreement with the State Water Resources Control Board. The contents of this document do not necessarily reflect the views and policies of the foregoing, nor does mention of trade names or commercial products constitute endorsement or recommendation for use.
If the most responsive and responsible bid amount exceeds the funds available, an amendment to the financing agreement with the State Water Resources Control Board must be ap- proved prior to begin- ning construction of the Project.
Award of Contract: District shall award
the Contract for the Project to the lowest responsible bidder as
determined from the base bid alone by the District. District re- serves the right to reject any or all bids or to waive any irregularities or informalities in any bids or in the bidding process. For further information, contact Black Water Consulting Engineers, Inc., Attn: Reid Johnson, P.E. at rj.jol2@gmail.com or (209) 629-9220.
END OF NOTICE INVITING BIDS July 14 & 21, 2022
CITY OF DINUBA Ordinance Summary
NOTICE IS HEREBY GIVEN that on June 28, 2022, the City Council of the City of Dinuba, California, adopted Ordinance No. 2022-5 entitled:
AN ORDINANCE OF THE CITY OF DINUBA, ADDING AND ADOPT- ING SECTION 2.25.010 ET SEQ ENTITLED “MILITARY EQUIP- MENT USE POLICY” TO THE DINUBA MUNICIPAL CODE IN COMPLIANCE WITH ASSEMBLY BILL 481 The proposed ordi- nance adopts a Military Equipment Use Policy for the Dinuba Police Department requiring it to obtain City Council approval for certain actions related to the Police Department us- ing military equipment. Among other things, the Policy and Ordinance requires (1) the Police Department to publish an annual report of each type of military equipment approved for use by the City Council (2) that City Council conduct an annual review of the Police Department’s Military Equipment Use Policy and to either renew, amend or disapprove use of certain military equipment and that
(3) the Police Depart- ment hold at least one community engagement meeting within 30 days of its submission of its annual report to City Council on the use of its military equipment.
The City Council adopted the ordinance Military Equipment Use Policy by the following vote:
AYES: Councilmem- bers Longoria, Nerio- Guerrero, Thusu, Vice Mayor Reynosa. NOES: None ABSTAIN: None ABSENT:Mayor Launer This notice contains
a general summary of Ordinance No. 2022-05 and complies with City Charter section 2.12(F) requiring publication
of an Ordinance or its summary within 20 days of adoption. For more information or
if you wish to view or request a full copy of the ordinance please contact the City Clerk’s office at 405 East El Monte Way, Dinuba CA or call (559) 591-5900. ATTEST: David Yanez, City Attorney
Published Date: Mid Valley Times, July 14, 2022
NOTICE OF PUBLIC HEARING CITY OF DINUBA DINUBA CITY COUNCIL
WHAT’S BEING PLANNED?
The Dinuba City Council is scheduled to hold a public hearing to consider the following proposal:Castle Rock Subdivision Project. When and Where? 6:30 pm, Tuesday, July 26, 2022
Council Chambers, Dinuba City Hall
405 E. El Monte Way Dinuba, CA 93618 Applicant:
• Castle Rock Communities, Inc.
Location:
On the east side of Randle Road (opposite Park Way) and the
west side of Road
92 (Assessor Parcel Number 018-180-031). Proposal:
A request for a zone change to apply
the Planned Unit Development (PUD) zone to a 15.8-acre
site and a request for approval of a Tentative Subdivision Map for the site for the development of a 71-lot single family residential subdivision and a 1.1-acre neighborhood park.
Notice is also given
that an environmental assessment has been conducted for the project identified above. The assessment
has determined
that the action will
not have potential adverse effects on
the environment and
a Mitigated Negative Declaration is proposed for adoption, consistent with the Guidelines
of the California Environmental Quality Act (CEQA).
Contact:
You are welcome to attend this meeting to express your views on this request. The City also accepts mailed comments, so they can be distributed to the City Council. If you desire more information or wish to view the staff report for the project(s), please contact the City of Dinuba Public Works Department, 1088 E. Kamm Avenue or by phone at (559) 591- 5924.
Published in the Mid Valley Times July 14, 2022
CITY OF SANGER NOTICE OF PLAN- NING COMMISSION PUBLIC HEARING
This Contract is not subject to prequalifica- tion pursuant to Public Contract Code section 20111.6.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Indus- trial Relations. For all projects over Twenty- Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to sub- mit a bid or to be listed in a bid proposal sub- ject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5
to perform public work as defined by Division 2, Part 7, Chapter 1
(§§ 1720 et seq.) of the Labor Code. For all projects over Twenty- Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1
(§§ 1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work. Contract Time shall
be Sixty (60) calendar days, and liquidated damages for delay shall accrue. See Agreement Between Owner and Contractor for more information.
Bids must be sealed and filed in the Busi- ness Office of the Owner at 1905 7th Street, Sanger, CA 93657, by July 28, 2022, before 3:00 p.m. on the clock designated by the Owner or its rep- resentative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted.
A non-mandatory pre- bid conference will be held on July, 21 2002, at 3:00 p.m. at Hallmark Charter School 2445 9th St, Sanger, CA 93657.
Bids must be accompa- nied by a bidder’s bond, cashier’s check, or cer- tified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Con- tract Documents, the successful bidder will be required to furnish
a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents. The successful bid-
der will be allowed to substitute securities or establish an escrow in lieu of retainage, pursu- ant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Condi- tions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in ac- cordance with the Cali- fornia Public Contract Code, providing for the licensing of contractors. In accordance with Sec- tion 3300 of said Code, the bidder shall have
a Class “B” license
and shall maintain that license in good stand- ing through Contract completion and all applicable warranty periods. For all projects over Twenty-five Thou- sand Dollars ($25,000), bidder shall state the public works contrac- tor registration number on the Designation of Subcontractors form
for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid.
The Director of Indus- trial Relations of the State of California, in the manner provided
by law, has ascertained the general prevail-
ing rate of per diem wages and rate for legal holidays and overtime
work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Copies of the required rates are on file at the Owner’s business office and are available on request. Advertise:1st Publica- tion Date
July 14, 2022 2nd Pub- lication Date
July 21, 2022
NOTICE BY THE SANGER CITY COUN- CIL
OF ITS INTENT TO ADOPT AN ORDI- NANCE
NOTICE IS HEREBY GIVEN that on July
7, 2022 at 6:00 p.m.
or as soon after as the matter may be heard,
at its regular meeting held at City Hall, 700 7th Street, Sanger, Cali- fornia, the City Council of the City of Sanger intends to adopt an Ordinance, entitled:
AN ORDINANCE OF THE CITY COUNCIL OF THE CITY OF SANGER REPEALING CHAPTER 82 OF AR- TICLE V AND ADDING NEW CHAPTER 82 TO ARTICLE V OF THE SANGER CITY CODE RELATING TO URBAN STORMWATER QUAL- ITY MANAGEMENT The proposed ordi- nance is to ensure health, safety, and general welfare of citizens, and to protect and enhance the quality of the city’s watercours- es, water bodies, and wetlands pursuant to and consistent with all applicable state and federal laws related to stormwater manage- ment, including, but not limited to, the clean wa- ter act (33 USC 1251 et seq.), the national pollu- tion discharge elimina- tion system regulations (40 CFR 122 et seq.) and the city’s stormwa- ter discharge permit for small municipal storm water systems (MS4). This article shall be known as and may be referred to as the “City of Sanger Urban Storm- water Quality Manage- ment Ordinance” and referred to in this article as “ordinance.”
A full version of the proposed Ordinance
is available at the City Clerk’s office at City Hall, 1700 7th Street, Sanger, CA 93657. A copy is also available on the City’s website at https://www.ci.sanger. ca.us/AgendaCenter (see City Council agen- da of July 7, 2022).
/s/ Rebeca Ramirez City Clerk
PUBLISHED: Mid Valley Times, July 14, 2022
NOTICE OF PETITION TO ADMINISTER ESTATE OF RAMIRO GOMEZ CASE NUMBER:
22CEPR00768
To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: RAMIRO GOMEZ
A Petition for Probate has been filed by: Erika Gomez in the Superior Court of California, County of Fresno
The Petition for probate requests that: Erika Gomez be appointed as personal representative to administer the estate of the decedent.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: 8/15/2022
Time: 9:00 A.M.
Dept.: 303
Address of court: 1130 “O” STREET, 3rd Floor, FRESNO, CA 93721, B.F. Sisk Courthouse
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.
If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for Petitioner: James D. Miller, Esq. RAIMONDO MILLER, A Law Corporation,
P.O. Box 28100 Fresno, CA 93729 July 14, 21 & 28, 2022
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202210003282
The Following Person is Conducting Business as Renewal (no Change(s) in facts from previous filing)
Fictitious Business Name:
S.S GILL EXPRESS
5815 E. GROVE AVENUE
FRESNO, CA 93727 FRESNO COUNTY
Full Name of Registrant: SUKHPAL SINGH GILL 5815 E. GROVE AVENUE
FRESNO, CA 93727 This business is conducted by: an individual
The registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 07/21/2017
I declare that all information in this statement is true and correct. ( A registrant who declares as true any material matter pursuant to Section 17913 of Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000)
Registrant’s Name SUKHPAL SINGH GILL, OWNER
Filed with the Fresno County Clerk on: JUN 15, 2022
James A. Kus County Clerk
By: Thang Yang, Deputy County Clerk
July 14, 21, 28 & August 4, 2022
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202210003310
The Following Person is Conducting Business as New (First Filing)
Fictitious Business Name: MARISCOS MICHELADAS MICH
702LST
SANGER, CA 93657 FRESNO COUNTY
Full Name of Registrant: MICHELADAS MICH LLC
702LST
SANGER, CA 93657
(If corporation or LLC, print number listed on Articles of Incorporation) 202005011014
This business is conducted by: limited liability company
The registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 04/01/2018
I declare that all information in this
statement is true and correct. ( A registrant who declares as true any material matter pursuant to Section 17913 of Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000)
Registrant’s Name YAJAIRA ZULET NEGRETE, OWNER Filed with the Fresno County Clerk on: JUN 16, 2022
James A. Kus County Clerk
By: Jessica Munoz, Deputy County Clerk July 14, 21, 28 & August 4, 2022
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202210003356
The Following Person is Conducting Business as New (First Filing)
Fictitious Business Name: CONSTRUCTION SERVICES INNOVATIONS
3939 KELLY CIR SELMA, CA 93662 FRESNO COUNTY (559) 397-8136
Full Name of Registrant: LUPE RENTERIA
3939 KELLY CIR SELMA, CA 93662
This business is conducted by: an individual
The registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 06/17/2022
I declare that all information in this statement is true and correct. ( A registrant who declares as true any material matter pursuant to Section 17913 of Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000)
Registrant’s Name LUPE RENTERIA, OWNER
Filed with the Fresno County Clerk on: JUN 17, 2022
James A. Kus County Clerk
By: Wendy Torres, Deputy County Clerk July 14, 21, 28 & August 4, 2022
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202210003361
The Following Person is Conducting Business as New (First Filing)
Fictitious Business Name: CLEAN SOLAR PLUS
9592 S LEONARD AVE SELMA, CA 93662 FRESNO COUNTY 5597378133
Full Name of Registrant: LUIS GUZMAN FERREL 9592 S LEONARD AVE SELMA, CA 93662
This business is conducted by: an individual
The registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
I declare that all information in this statement is true and correct. ( A registrant who declares as true any material matter pursuant to Section 17913 of Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000)
Registrant’s Name LUIS GUZMAN, OWNER Filed with the Fresno County Clerk on: JUN 17, 2022
James A. Kus County Clerk
By: Cierra Loera, Deputy County Clerk
July 14, 21, 28 & August 4, 2022
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202210003394
The Following Person is Conducting Business as New (First Filing)
Fictitious Business Name:
SJV APPAREL
3904 N ANN AVE FRESNO, CA 93727 FRESNO COUNTY (559) 347-9766
Full Name of Registrant: SJV APPAREL INC 3904 N ANN AVE FRESNO, CA 93727
(If corporation or LLC,
Thursday, July 14, 2022 | A15 | Mid Valley TiMes PUBLIC NOTICES
NOTICE IS HEREBY GIVEN that the Plan- ning Commission of the City of Sanger (“City”) will hold a public hear- ing at its meeting on July 28, 2022, at 6:00 pm, in the City Council Chambers located
at 1700 7th Street or as soon thereafter as possible, to consider public testimony for the following:
Zoning Amendment No. 2022–02, application filed by Vermeltfoort Architect, Inc.: Zoning Amendment request- ing zoning designation change from Commu- nity Commercial (C–2) to General Commer- cial (C-4) for Asses- sor’s Parcel Number 315-021-23, property located on north side of Jensen Avenue west of N. Bethel Ave., Sanger, CA 93657, as well as a California Environmen- tal Quality Act (CEQA) Finding of Consistency with the 2035 General Plan and Environmental Impact Report (EIR) (SCH #2018031047). Members of the public may attend the public hearing in person or
by teleconference. The weblink and telephone number listed below will provide access to the City Council meeting. All interested parties are invited to submit statements orally or
in writing. Written comments must be delivered to the City Clerk’s Office prior to the scheduled hearing date. Public comments will also be accepted via email at publicmeet- ing@ci.sanger.ca.us prior to the close of the public hearing. Weblink: _________________ Telephone number: 1-669-900-9128 Meeting ID: ______________ DATED: July 14 , 2022
NOTICE TO BIDDERS
Notice is hereby given that Sanger Unified School District (here- inafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the Contract to construct:
PROJECT #1000-23- 001 RELOCATABLES BUILDINGS AND SITE IMPROVEMENTS AT HALLMARK CHAR- TER SCHOOL 2445 9TH STREET SANGER, CA 93657
as per drawings and specifications which may now be obtained electronically from the Architect:
MANGINI ASSOCI- ATES INC. 4320 W MINERAL KING AVE VISALIA, CA 93291 (559) 524-7170
upon deposit of Two-Hundred Dollars ($200.00) refundable when drawings and specifications are returned in good condi- tion as indicated in the “Instruction to Bidders.” The lowest bid shall
be determined on the amount of the base bid.