Page 14 - Mid Valley Times 4-9-20 E-edition

Mid Valley Times B54 Thursday, April 9, 2020 PUBLIC NOTICES
NOTICE TO BIDDERS
Notice is hereby given that sealed bids will be received by the City Council of the City of Reedley for furnishing all labor, materials, services, and equipment and performing all work necessary for the REEDLEY CITY STREET IMPROVEMENTS (PHASE IX), BUTTON- WILLOW AVENUE WIDENING, CDBG PROJECT NO. 18571 in the City of Reedley, Fresno County.
Project plans, special provisions, bid and contract documents are on le and may be examined at the City’s website www.reedley.ca.gov and at the Of ce of the City Engineer, 1733 Ninth Street, Reedley, California, 93654, (559) 637-4200, ext. 295. Copies may also be examined at the following Builders Exchanges:
•Central California Builders Exchange •Tulare-Kings Builders Exchange •McGraw-Hill Construction Dodge •Construction Bid Board
Construction Bid Copies may be obtained at the City of Reedley for a charge of FORTY FIVE dollars ($45.00) per set, nonrefundable.
In addition, there will be a ten dollar ($10.00) mailing and handling charge for any sets mailed. Prospective bidders must be on the plan holders list in order to submit a bid proposal and to receive any ad- dendums issued by the City of Reedley.
Description of Work: The work includes, in general, underground utility and trenching, boring and jacking conduit, installation of under- ground electrical conduits, underground vaults, installation of curb, gutter, sidewalk, curb ramp, driveway approach, street lighting, land- scape and irrigation, a 10-inch water main, water service connection and roadway pavement.
This work shall be diligently prosecuted to completion before the expiration of FIFTY (50) CONSECUTIVE WORKING DAYS on the tenth calendar day after approval of the contract.
The City of Reedley hereby noti es all bidders that it will af rmatively insure that in any contract entered into pursuant to this advertise- ment, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religious creed, sex, or national origin in consideration for an award.
The DBE contract goal is 7 percent.
The prevailing wage rates as determined by the Director of Industrial Relations of the State of California shall apply to this project. In accordance with the provisions of Section 1770 of the Labor Code, the Director of the Department of Industrial Relations of the State
of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for Section 1773.8 of the California Labor Code, apprenticeship or other training programs authorized by Section 3093 of said code, and similar purposes ap- plicable to the work to be done. Said wages are on le with the City of Reedley and County of Fresno and are incorporated herein as part of the special provisions. By submission of a bid, bidder stipulates and agrees to abide by the provisions of the Labor Code related
to payment of prevailing wage or promptly pay a penalty of $50.00 per day per worker paid less than prevailing wage pursuant to the provisions of Labor Code Section 1775. A work day shall not exceed eight hours labor per day or forty (40) hours labor per week. The successful bidder shall keep an accurate record of employees’ hours worked by calendar day and week.
The work to be performed under this contract is on a project assisted under a program providing direct Federal nancial assistance from the Department of Housing and Urban Development, Community De- velopment Block Grant Program, and is subject to the requirements of Section 3 of the Housing and Urban Development Act of 1968,
as amended, 12 USC 170lu. Section 3 requires that to the greatest extent feasible opportunities for training and employment be given to low and very low income persons residing within the project area and that the contracts for work in connection with the project be awarded to eligible business concerns which are located in, or owned in sub- stantial part by persons residing in the area of the project. Regula- tions for implementing the Section 3 clause are contained in 24 CFR 135, as amended, and as speci ed in the project speci cations.
All pages of the Preliminary (Anticipated) Statement of Work Force Needs form, also contained in the project speci cations, will be required to be completed and submitted prior to award. All pages of the Final (Completion) Statement of Work Force Needs form shall also be required to be completed and submitted upon completion of construction.
Minimum wage rates for this project, as predetermined by the Secre- tary of Labor, are set forth herein in the bid and contract documents and incorporated as part of the special provisions. These wage rates may be examined at the City of Reedley where the project plans, special provisions, bid and contract documents may be seen. If there is a difference between the minimum wage rates predeter- mined by the Secretary of Labor and the prevailing wage rates deter- mined by the Director of the Department of Industrial Relations of the State of California for similar classi cations of labor, the Contractor and his subcontractors shall pay not less than the higher wage rate. Bids must be led with the Reedley City Engineer, 1733 Ninth Street, Reedley, not later than 3:00 p.m., Thursday May 14,
2020, at which time the Of ce of the City Engineer of the City of Reedley will open said bids. Bids must be submitted in a sealed envelope and marked on the outside of the envelope “REEDLEY CITY STREET IMPROVEMENTS (PHASE IX), BUTTONWILLOW AVENUE WIDENING, CDBG PROJECT NO. 18571” together with the name and address of the bidder. The bids will be opened and read publicly at that time.
Each bid must be accompanied by either a cashier’s check, certi ed check or bidder’s bond in a sum equal to at least ten (10%) percent of the total amount bid. Checks or bonds must be made payable
to the City of Reedley; such securities shall be a guarantee that the bidder, if his bid is accepted, will enter into a satisfactory contract and furnish a good and suf cient bond for faithful performance thereof and for payment of labor and material costs in accordance with the requirements of the plans and speci cations.
No contract will be awarded to a Contractor who has not been li- censed in accordance with the provisions of Chapter 791, Statutes of 1929, as amended, or whose bid is not on the proposal form included in the contract documents. An appropriate and valid California Contractor’s License is required for the project. Class A General Engineering Contractors license is required.
No contractor or subcontractor may be listed on a bid proposal for
a public works project (submitted on or after March 1, 2015) unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5 [with limited exceptions from this require- ment for bid purposes only under Labor Code section 1771.1(a)].
No Contractor or subcontractor may be awarded a contract for public work on a public works project (awarded on or after April 1, 2015) un- less registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5.
This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations.
Interpretations: All questions about the meaning or intent of the Con- tract Documents shall be directed to the of ce of the City Engineer in writing. Interpretations or clari cations considered necessary by the City Engineer in response to such questions will be resolved by the issuance of addenda delivered to all parties listed on the plan holders list. Questions received less than 3 business days prior to the date of opening bids shall be considered nonresponsive and therefore
not addressed. Only questions that have been resolved by formal written addenda shall be binding. Oral and other interpretations or clari cations will be without legal or contractual effect.
The City reserves the right to reject any or all bids, to waive any informality in bids received, or to award the contract to the lowest responsible bidder complying with these instructions as may serve the best interest of the City of Reedley. The City reserves the right
to award the contract to other than the lowest bidder if it appears that the best interests of the City of Reedley will be served thereby.
BY THE ORDER OF THE CITY COUNCIL OF THE CITY OF REED- LEY
April 9,2020
Si requiere la traducción al español de este aviso, por favor contacte a Corina Tamez, secretaria administrativa, al (559) 876-6300, ext. 1500, o ctamez@ci.sanger.ca.us.
NOTICE OF PUBLIC HEARING
NOTICE IS HEREBY GIVEN that the Planning Commission the City of Sanger, California will hold a public hearing at a regularly sched- uled meeting to be held at 6:00 p.m., Thursday, April 23, 2020 at the City Hall Council Chambers, 1700 7th Street Sanger, California, to consider the following:
Conditional Use Permit No. 2020-01 – Minor Conditional Use Permit, led by Anthony, Espitia, Phat Al’s: Minor Revision to exist- ing Conditional Use Permit No. 2016-01, to allow replacement of a California Department of Alcoholic Beverage Control, License Type 42 – On Sale Beer & Wine – Public Premises, with a License Type 48 – On Sale General – Public Premises, at Phat Al’s, 1316 7th Street, Sanger, CA, 93657, APN 317–104–17, as well as a Class
1 Categorical Exemption under CEQA Guidelines Section 15301 (Existing Facilities).
This meeting will be conducted pursuant to the provisions of Paragraph 11 of the Governor’s Executive Order N-25-20 which suspends certain requirements of the Ralph M. Brown Act, and as a response to mitigating the spread of COVID-19, the meet- ing will not be open to the public. The weblink and telephone number listed below will provide access to the Planning Com- mission meeting via teleconference. Comments will also be accepted by email at dbrletic@ci.sanger.ca.us.
Please note that when joining the meeting you will also be asked to provide a participant number or name, which will be used to identify you during any public comment period. Weblink: https://zoom.us/j/940097824
Telephone number: 1 669 900 9128
Meeting ID: 940 097 824
All interested parties are invited to participate and to provide testi- mony either orally or in writing on Conditional Use Permit No. 2020- 1. If you have written comments on the project please submit them to David Brletic, Senior Planner, 1700 7th Street, Sanger, CA 93657. Comments (including video comments) may also be emailed to dbrletic@ci.sanger.ca.us. Telephone inquiries may also be directed to David Brletic, at 559-876-6300, extension 1540. Please note that your comments must be received by the City no later than by the close of the public hearing on Thursday, April 23, 2020 in order to be considered. If you challenge the project in court, you may be limited to raising only those issues you or someone else raised during the public comment described in this notice prior to the close of the public comment period.
Staff reports on these matters will be available to the public at least three days prior to the hearing and may be reviewed at City Hall located at 1700 7th Street, Sanger CA.
Si requiere la traducción al español de este aviso, por favor contacte a Corina Tamez, secretaria administrativa, al (559) 876-6300, ext. 1500, o ctamez@ci.sanger.ca.us.
April 9, 2020
NOTICE OF PRIVATE SALE
The following property will be sold by written bid by 9:00 a.m. MST on
4/12/2020.
2016 Peterbilt 579 1XPBD49X0GD308159 To inquire about this item please call Bret Swenson at 801-624-5864. Transportation Alliance Bank 4185 Harrison Blvd Ogden, UT 84403
April 2, 9, 2020
-NOTICE OF LIEN SALE-- Sanger Mini Storage 110 Academy Ave Sanger, CA 93657 559-875-5922 Pursuant to Chapter 10, commencing with 21700 of Business Professionals
code,
NOTICE IS HEREBY GIVEN, that Sanger Mini Storage will sell to the public by Online Auction commencing at 10 a.m. 5-1-20
The property described as General Household Items, Outdoor Activities, Recreation @ Miscellaneous, Personal Property, Children Items, Beauty Supplies, Books and Furniture.
The following occupants D11 GANDARA, ANGELICA
P21 MONTES, CHRISTINA L26 DEL REAL VERONICA
April 9, 16, 2020
ORDER TO SHOW CAUSE FOR CHANGE OF NAME PETITION OF Kallie Sierra Johnson FOR CHANGE OF NAME
CASE NUMBER: 282321 TO ALL INTERESTED
PERSONS:
Petitioner: Kallie Sierra Johnson filed a petition with this court for a decree changing name as follows: Present Name
Kallie Sierra Johnson Proposed Name
Kallie Sierra Tenhet
THE COURT ORDERS that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.
NOTICE OF HEARING
a. Date: April 23, 2020 Time: 8:30 AM Dept.: 7
b. The address of the court Superior Court of California, County of Tulare
221 S. Mooney Blvd. Rm 201
Visalia, CA 93291
Visalia Division
A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this count: Dinuba Sentinel/ Mid Valley Times
Date: March 5, 2020 Signed /s/ David C. Mathias Judge of the Superior Court March 19, 26, April 2, 9, 2020
AMENDED ORDER TO SHOW CAUSE FOR CHANGE OF NAME PETITION OF Stephanie Espino FOR CHANGE OF NAME
CASE NUMBER: VCU280564
TO ALL INTERESTED
PERSONS:
Petitioner: Stephanie Espino
filed a petition with this court for a decree changing name as follows:
Present Name
Kaylee Aleha Carrillo Proposed Name
Kaylee Aleha Espino
THE COURT ORDERS that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.
NOTICE OF HEARING
a. Date: April 30, 2020 Time: 8:30 AM Dept.: 7
b. The address of the court Superior Court of California, County of Tulare
221 S. Mooney Blvd. Rm 201
Visalia, CA 93291
Visalia Division
A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this count: Dinuba Sentinel/ Mid Valley Times
Date: March 5, 2020 Signed /s/ David C. Mathias Judge of the Superior Court March 19, 26, April 2, 9, 2020
CITATION FOR PUBLICATION UNDER WELFARE AND INSTITUTIONS CODE SECTION 294 CASE NAME: Julian Calderon
Case Number: J17-70865
1. To Lorena Calderon & Fabian Calderon Sr. and anyone claiming to be a parent of: Julian Calderon born on: November 23, 2019 at Adventist Health, Reedley CA
2. A hearing will be held on: May 27, 2020 at: 8:30am in Dept.: A
located at Superior Court of California, County of Tulare 11200 Avenue 368, Visalia, CA 93291 Juvenile Court
3. At the hearing the court will consider the recommendations of the social worker or probation officer.
4. The social worker or probation officer will recommend that your child be freed from your legal custody so that the child may be adopted. If the court follows the recommendation, all your parental rights to the child will be terminated.
5. You have the right to be present at the hearing, to present evidence, and you have the right to be represented by an attorney. If you do not have an attorney and cannot afford to hire one, the court will appoint an attorney for you. 6. If the court terminates your parental rights, the order may be final.
7. The court will proceed with this hearing whether or not you are present.
Date: March 3, 2020
by Signed /s/ Sandy Sheets, Admin Aide.
April 2,9,16, 23, 2020
STATEMENT OF ABANDONMENT OF USE OF FICTITIOUS BUSINESS NAME STATEMENT
File No. 2201510006005
The following person has abandoned the use of the following fictitious business name of:
Cedar Water
At business address:
1432 N. Cedar Ave Suit 109 Fresno, CA 93703 Fresno County
The fictitious business name referred to above was filed in the office of the Fresno County Clerk on: November 1, 2015
The full name and residence of the person abandoning the use of the listed fictitious business name
Sao Cheng Cha
5835 W. Santa Ave
Fresno, CA 93722
"I declare that all information in this statement is true and correct. ( A registrant who declares as true information which he or she knows to be false is guilty of crime.)" Signed: /s/ Cristina Garcia
The abandonment was filed with the Fresno County Clerk on: January 27, 2020 Brandi L. Orth, County Clerk By: Jessica Munoz, Deputy. March 19, 26, April 2, 9, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001259 The following person(s) is(are) conducting business
as:
BLARE Media, 7081 N. Marks Ave., #104-322, Fresno, CA 93711, County of Fresno
Registrant:
Jennifer Barnett, 7081 N. Marks Ave., #104-322, Fresno, CA 93711 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 04/11/2009 This business is conducted by: individual
Articles of Incorporation: This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information,
false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Jennifer Barnett, Owner Filed with the Fresno County Clerk on February 27, 2020 A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New filing
3/19, 3/26, 4/2, 4/9/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001336 The following person(s) is(are) conducting business
as:
MAACO, Collision Repair Services & Auto Painting, 1208 Barstow Ave., Clovis, CA 93612, County of Fresno Registrant:
TD Automotive Inc., 13446 Perry Dr., Visalia, CA 93292 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Corporation
Articles of Incorporation: C4305626
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Thomas Loveall, President
Filed with the Fresno County Clerk on March 3, 2020
A new Fictitious Business Name Statement must be
filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
3/19, 3/26, 4/2, 4/9/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001334 The following person(s) is(are) conducting business
as:
Dollar General Store #15336, 6459 N. Blackstone Ave., Fresno, CA 93710, County of Fresno Mailing address: 100 Mission Ridge, Goodlettsville, TN 37072
Registrant:
Dolgen California, LLC, 100 Mission Ridge, Goodlettsville, TN 37072 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 07/26/2014 This business is conducted by: Limited Liability Company
Articles of Incorporation: 201033610164
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Steven R. Deckard, CEO Filed with the Fresno County Clerk on March 3, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New filing
3/19, 3/26, 4/2, 4/9/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001396 The Following Person is
Conducting Business as New Filing
Fictitious Business Name:
Sheena Janitorial Service 4748 E. Cetti Ave, Fresno, CA 93702 Fresno County
(559) 704-9912
Mailing Address
4748 E. Cetti Ave,
Fresno, CA 93702
Full Name of Registrant
Sheena H. Capuchin 4748 E. Cetti Ave, Fresno, CA 93702 Registrant commenced to transact business under the Fictitious Business Name listed above on: March 5,
2020.
This business conducted by: Individual
Type or Print Signature and Title
Sheena H. Capuchin, Owner Filed with the Fresno County Clerk on: March 5, 2020 Brandi L. Orth, County Clerk By: Andrea Lopez, Deputy Notice: This Statement Expires On: March 4, 2025 A new statement must be filed prior to the expiration date.
March 19, 26, April 2, 9, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001474 The Following Persons are Conducting Business as
New Filing
Fictitious Business Name:
JR’s Smoke Shop 4942 E Ashlan Ave, Fresno, CA 93726 Fresno County
Mailing Address
4942 E Ashlan Ave, Fresno, CA 93726 Full Name of Registrant
Yahya Salah Alsoufi 2646 N. Cecilia Ave, Fresno, CA 93722 Ahmed Mused Nasher 3320 W Jensen Ave, Fresno, CA 93706 Registrant has not yet commenced to transact business under the Fictitious Business Name listed above. This business conducted by:
Copartners
Type or Print Signature and Title
Yahya Salah Alsoufi, Copartner
Filed with the Fresno County Clerk on: March 9, 2020 Brandi L. Orth, County Clerk By: Dakota Thurston, Deputy Notice: This Statement Expires On: March 8, 2025 A new statement must be
filed prior to the expiration date.
March 19, 26, April 2, 9, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001453 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Bebe Bapu Transport 3661 W Shields Ave Apt #286, Fresno, CA 93722 Fresno County (765) 236-7048
Mailing Address
3661 W Shields Ave Apt #286, Fresno, CA 93722
Full Name of Registrant
Kulbir Singh
3661 W Shields Ave Apt #286, Fresno, CA 93722 Registrant commenced to transact business under the Fictitious Business Name listed above on: March 9,
2020.
This business conducted by: Individual
Type or Print Signature and Title
Kulbir Singh, Owner
Filed with the Fresno County Clerk on: March 9, 2020 Brandi L. Orth, County Clerk By: Andrea Lopez, Deputy Notice: This Statement Expires On: March 8, 2025 A new statement must be filed prior to the expiration date.
March 19, 26, April 2, 9, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010001309 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
JN Handyman 7242 E Dayton Avenue, Fresno, CA 93737 Fresno County 559-269-0504
Mailing Address
7242 E Dayton Avenue, Fresno, CA 93737 Full Name of Registrant
Jose Angel Narvaez Monjaraz
7242 E Dayton Avenue, Fresno, CA 93737 Registrant has not yet commenced to transact business under the Fictitious Business Name listed above. This business conducted by:
Individual
Type or Print Signature and