Page 21 - RBK&C Attachments 28-5-16 (77pp)

Seventh Recital and Schedule 3
Supplemental Provisions
Collaborative working Health and safety
Cost savings and value improvements
Sustainable development and environmental considerations
Performance Indicators and monitoring
Notification and negotiation of disputes
Arbitration
CDM Planning Period
Date for Commencement of the Works
Date for Completion Liquidated damages
Rectification Period
Percentage of the total value of work etc.
Percentage of the total amount to be paid to the contractor
Supply of documentation for computation of amount to be finally certified
Contribution, levy and tax changes
Article 7 1.1
2.2
2.2 2.8
2.10 4.3 4.4 4.8.1
4.11 and Schedule 2
Paragraph 1 applies Paragraph 2 applies Paragraph 3 applies
Paragraph 4 applies
Paragraph 5 does not apply
Paragraph 6 does not apply
Article 7 and Schedule 1 (Arbitration) apply
Shall mean the period of two weeks ending on the Date of Commencement of the Works
To be agreed
To be agreed
At the rate of £750 per week
Six months from the date of practical completion
95 per cent 971⁄2 per cent Six months
To be deleted
4