Page 245 - FINAL MASTER 616pp 20-6-19 SOUND

B Form of Contract The Form of Contract will be the JCT Minor Works Building Contract, 2005 edition, as amended by Amendment 1, issued April 2007. The following insertions and deletions are to be made in the Contract Particulars:- Clause etc. New Fourth Recital (see Amendment 1) Fifth Recital (previously Fourth Recital) Article 7 1.1 (see Amendment 1) 2.2 2.2 2.8 2.10 4.3 4.5 4.8.1 4.11 and Schedule 2 5.3.2 5.4A, 5.4B & 5.4C (see Amendment 1) 5.4A.l and 5.4B.1.2 7.2 Adjudication Schedule 1 (paragraph 1) and Schedule 2 (paragraphs 1.1, 1.2, 1.5, 1.6, 2.1 and 2.2) Schedule 1 (paragraph 2.1) Subject Construction Industry Scheme (CIS) CDM Regulations Regulations apply Arbitration CDM Planning Period Date for Commencement of the Works Date for Completion Liquidated damages Rectification Period Percentage of the total value of work etc. Percentage of the total amount to be paid to the contractor Supply of documentation for computation of amount to be finally certified Contribution, levy and tax changes Contractor's insurance - injury to persons or property. Insurance cover (jor anyone occurrence or series of occurrences arising out of one event) occurrences arising out of one event) Insurance of the Works etc. - alternative provisions Percentage to cover professional fees Nominator of Adjudicator Base Date Arbitration Appointment of Arbitrator (and of any replacement) Employer at the Base Date is not a 'contractor' for the purposes of the CIS All the CDM Article 7 and Schedule 1 (Arbitration) apply Shall mean the period of four weeks ending on the Date of Commencement of the Works To be agreed To be agreed At the rate of £300 per week 6 months from the date of practical completion 95 per cent 97.5 per cent 3 months To be deleted £5 million Clause 5.4B (Works and existing structures insurance by Employer in Joint Names) applies 15 per cent President or a Vice- President of The Royal Institution of Chartered Surveyors The date of the contractor's tender President or a Vice- President of The Royal Institution of Chartered Surveyors 3