Page 12 - Mid Valley Times 11-5-20 E-edition

Thursday, November 5, 2020 | A12 | Mid Valley TiMes PUBLIC NOTICES
Si requiere la traducción al español de este aviso, por favor contacte a Corina Tamez, secretaria administrativa, al (559) 876- 6300, ext. 1500, o ctamez@ci.sanger.ca.us.
NOTICE OF PUBLIC HEARING
NOTICE IS HEREBY GIVEN that the Sanger City Council will hold a public hearing on Thursday, November 19, 2020, at 6:00 p.m. in the Sanger City Hall Council Chamber located at 1700 7th Street, Sanger, California, as part of the citizen participation process, to dis- cuss a possible application for a Grant from the U.S. Department of Commerce for Funding through the Economic Development Ad- ministration for the Construction of utility infrastructure in the North
Academy Area.
The purpose of the public hearing will be to consider an application for funding from the U.S. Department of Commerce through the Eco- nomic Development Administration for the Construction of utility infra- structure in the North Academy Area. Funding from this grant will al- low for the development of a new water well and of a sewer line from Quality Avenue to Academy Avenue and northbound to State Route 180. The project will also consider the development of additional water lines for the completion of a looped water system if necessary. Development of these utilities will provide services to future commer- cial development in the Academy Avenue area.
This meeting will be conducted pursuant to the provisions of Para- graph 11 of the Governor’s Executive Order N-25-20 which suspends certain requirements of the Ralph M. Brown Act, and as a response to mitigating the spread of COVID-19, the meeting will not be open to the public. The weblink and telephone number listed below will pro- vide access to the Planning Commission meeting via teleconference. Comments will also be accepted by email at tnavarro@ci.sanger.ca.us.
Please note that when joining the meeting you will also be asked to provide a participant number or name, which will be used to identify you during any public comment period.
Weblink: https://us02web.zoom.us/j/82487000449 Meeting ID: 824 8700 0449
Phone: 1-669-900-9128
All interested parties are invited to participate and to provide testi- mony either orally or in writing on the U.S. Department of Com- merce Funding through the Economic Development Administration. If you have written comments on the project please submit them to Tom Navarro, Community Development Director, 1700 7th Street, Sanger, CA 93657. Comments (including video comments) may also be emailed to tnavarro@ci.sanger.ca.us. Telephone inquiries may also be directed to Tom Navarro, at 559-876-6300, extension 1520. Please note that your comments must be received by the City no later than by the close of the public hearing on Thursday, November 19, 2020 in order to be considered. If you challenge the project in court, you may be limited to raising only those issues you or someone else raised during the public comment described in this notice prior to the close of the public comment period.
Si requiere la traducción al español de este aviso, por favor contacte a Corina Tamez, secretaria administrativa, al (559) 876- 6300, ext. 1500, o ctamez@ci.sanger.ca.us.
Rebeca Padron, City Clerk
November 5, 2020
NOTICE OF INTENT TO ADOPT A MITIGATED NEGATIVE DEC- LARATION ALTA AVENUE
(ROAD 80) AND NEBRASKA AVENUE (AVENUE 424) ROUNDABOUT PROJECT
NOTICE IS HEREBY GIVEN that City of Dinuba (City, Lead Agency) plans to adopt a Mitigated Negative Declaration for the Alta Avenue (Road 80) and Nebraska Avenue (Avenue 424) Roundabout Project. The public hearing will be held by the City Council on December 8, 2020 at 6:30pm at City Hall located at 405 E. El Monte Way, Dinuba,
CA 93618.
The proposed project consists of constructing a single lane round- about at the intersection of Alta Avenue (Road 80) and Nebraska Avenue (Avenue 424). The project will include concrete curb and gut- ter, sidewalk, median islands, landscape and irrigation, storm drain facilities, and other miscellaneous street improvements. The project is located at the intersection of Alta Avenue (Road 80) and Nebraska Avenue (Avenue 424), in the City of Dinuba, within the County of Tulare.
Pursuant to the California Environmental Quality Act (CEQA), an Ini- tial Study/Negative Declaration has been prepared, describing the degree of potential environmental impacts of the proposed project. The City has assessed the potential environmental impacts of this proposed project and has determined that there will be no impact to the environment. Copies of the Initial Study and proposed Mitigated Negative Declaration are on le for public review at (Public Works Department, 1088 E. Kamm Ave., Dinuba, CA 93618). The public re- view during which the City will receive comments on the Proposed Mitigated Negative Declaration will begin on October 29, 2020 and end on November 30, 2020. Comments should be in writing, if pos- sible, and addressed to Jason Watts at Yamabe & Horn Engineering, Inc., 2985 N. Burl Ave., Ste #101, Fresno, CA 93727, or at jwatts@ yhmail.com.
The site has been reviewed in accordance with Government Code Section 65962.5 and is not listed as a hazardous waste or materials site.
October 29, November 5, 2020
SUMMARY OF ORDINANCE NO. 2020-04
AN ORDINANCE OF THE CITY COUNCIL OF THE CITY OF DINUBA AMENDING THE ZONING OF PARCELS LOCATED ON THE NORTH SIDE OF EAST EL MONTE WAY BETWEEN THE EXISTING CITY LIMIT BOUNDARY AND ROAD 92
THE CITY COUNCIL OF THE CITY OF
DINUBA HEREBY DOES ORDAIN:
SECTION 1. FINDINGS.
(a) The City of Dinuba administers a Zoning Ordinance (Title 17 of the Dinuba Municipal Code), including a map that designates all parcels of land with speci c zoning classi cations for the purposes of facilitat- ing a well-planned City and to avoid land use con icts among other objectives.
(b) The City has initiated the annexation of nine parcels (and portions of parcels: APNs 013-090-023, 013-090-024, 013-090-039, 013-090- 040, 013-090-043, 013-090-044, 013-090-046, 013-090-049 and 013-090-050) containing approximately 8.5± acres along the north side of E. El Monte Way between the existing city boundary on the west and Road 92 on the east.
(c) The purpose of the zone change is to apply City zoning to the parcels upon their annexation.
This Ordinance shall take effect and be in full force thirty {30) days from and after its adoption. The foregoing Ordinance No. 2020-04 was introduced at a regular meeting of the City Council of the City of Dinuba on the 13th day of October, 2020, and adopted on the 28th day of October, 2020 by the following vote:
AYES: COUNCIL MEMBERS: Reynosa, Launer, Thusu
ABSENT: COUNCIL MEMBERS: Morales, Longoria
A full copy of the Ordinance is available for viewing at Dinuba City Hall in the City Clerk’s of ce.
November 5, 2020
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT District Of ce
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Uni ed School District (hereinafter referred to as “Own- er”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the
Bid No. 2008 Security Camera Installation at Various Sites as per drawings and speci ca- tions which may now be obtained
electronically from the District.
The lowest bid shall be deter-
mined on the amount of the base
bid. This Contract is not subject to
prequali cation pursuant to Public
Contract Code section 20111.6.
Public works projects shall be
subject to compliance monitor-
ing and enforcement by the De-
partment of Industrial Relations.
For all projects over Twenty-Five
Thousand Dollars ($25,000), a
contractor or subcontractor shall
not be quali ed to submit a bid or
to be listed in a bid proposal sub-
ject to the requirements of Pub-
lic Contract Code section 4104
unless currently registered and
quali ed under Labor Code sec-
tion 1725.5 to perform public work
as de ned by Division 2, Part 7,
Chapter 1 (§§ 1720 et seq.) of
the Labor Code. For all projects
over Twenty-Five Thousand Dol-
lars ($25,000), a contractor or
subcontractor shall not be quali-
ed to enter into, or engage in the
performance of, any contract of
public work (as de ned by Divi-
sion 2, Part 7, Chapter 1 (§§ 1720
et seq.) of the Labor Code) unless
currently registered and quali ed
under Labor Code section 1725.5
will be disquali ed.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certi ed check for at least ten per- cent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Docu- ments, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred per- cent (100%) of the Contract Sum, as set forth in the Contract Docu- ments.
The successful bidder will be al- lowed to substitute securities or establish an escrow in lieu of re- tainage, pursuant to Public Con- tract Code Section 22300, and as described in the Agreement Be- tween Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do busi- ness in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a C7 license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty- ve Thousand Dollars ($25,000), bid- der shall state the public works contractor registration number on the Designation of Subcontrac- tors form for each subcontractor
Contract to construct:
to perform public work.
Contract Time shall be from De-
cember 14, 2020 to February performing more than one-half of
26, 2021 (75) calendar days,onepercent(0.5%)ofthebidder’s
and liquidated damages for delay total bid.
shall accrue.
Bids must be sealed and led at the Educational Support Center at 1801 10th St, Reedley, California 93654 by November 23, 2020 at 2:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted. Mandatory pre-bid conference will be held on November 16, 2020, at 9:00 a.m. at various sites be- ginning at the District Operations Center, 1500 I Street, Reedley California, 93654. Bidders not attending the pre-bid conference
The Director of Industrial Rela- tions of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classi ed in an amount not less than the rates speci ed. Copies of the required rates are on le at the Owner’s business of ce and are available on request.
John G. Campbell, Superinten-
dent.
November 5, 12, 2020
Invitation to Bid
The Board of Trustees of Cutler-Orosi Joint Uni ed School District. Tulare County in California invites and will receive sealed proposals for adding a server room to the existing administration building at El Monte Middle School located at 42111 Road 128 Orosi CA. 93647. The school district will receive the bids up to but no later than 10:30 am, December 2, 2020 Thereafter said bids will be opened and read aloud. Bids received after this time will be returned unopened. Con- tractor will follow all California public work prevailing wage laws. Bids shall be valid for 60 calendar days after the bid opening date. All bids shall be delivered to the Cutler-Orosi Joint Uni ed School District of- ce located at 12623 Avenue 416, Orosi CA 93647.
A non-mandatory pre-bid conference will be conducted at the Dis- trict of ce at the above address on November 10, 2020 at 10:00 am. Drawings and Bid Documents for the project can be obtained at the of ce of Marvin Armstrong Architect, 1640 W. Shaw Suite 102, Fresno CA 93711, or by calling 559-229-9950 or email: marvin@ma- architect.com.
Bids must be accompanied by a cashier’s check, or a Bid Bond in favor of the District in an amount not less than ten (10%) of the sub- mitted total bid price of the bidder’s category. Successful bidders will comply with all California public labor laws regarding prevailing wage and bonding requirements the board reserves the right to reject any or all bids.
October 29, November 5, 2020
NOTICE REGARDING PREQUALIFICATION FOR CUTLER-OROSI JOINT UNIFIED SCHOOL DISTRICT Notice is hereby given by Cutler-Orosi Joint Uni ed School District (“District”) that general contractors, mechanical, electrical and plumb- ing subcontractors planning to submit a bid or proposal for qualify- ing District projects (each a “Project”) in the twelve months follow- ing prequali cation will be required to prequalify pursuant to Public Contract Code § 20111.6 prior to bidding or submitting a proposal. Prequali cation application packages are available on the District’s website or at the District’s of ce located at: 12623 Avenue 416 Orosi, CA 93647. Prequali cation application packets must be completed and returned to the District’s of ce no later than 1:00 p.m., December
23rd, 2020.
This prequali cation packet includes a questionnaire and nancial statement, to be veri ed under oath. The District will use the informa- tion and documentation required by the packet to prequalify general contractors, mechanical, electrical and plumbing subcontractors in accordance with applicable law.
November 5, 12, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF Joe Marquez CASE NO. VPR050243 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: Joe
Marquez
A Petition for Probate has been filed by: Mary L. Diaz in the Superior Court of California, County of Tulare. The Petition for probate requests that Mary L. Diaz be appointed as personal representative to administer the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: November 23, 2020 Time: 10:00 A.M.
Dept.: 7
Address of court: 221 South Mooney Blvd, Couunty Civic Center Visalia, CA 93291 Visalia Probate
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable
in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for petitioner: Nichola G. Krebsbach
220 S. Mooney Blvd., Ste B Visalia, CA 93291
October 22, 29, November 5, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF Theodora Gaspar Decedent CASE NO. VPR050273 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both,
of: Theodora Gaspar
A Petition for Probate has been filed by: Cristal & Adrien Rodriguez in the Superior Court of California, County of Tulare.
The Petition for probate requests that Cristal & Adrien Rodriguez be appointed as personal representative to administer
the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: December 2, 2020 Time: 10:00 A.M.
Dept.: 7
Address of court: 221 South Mooney Blvd, Room 201 Visalia, CA 93291 Visalia Probate Division
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable
in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for petitioner: Jeffrey T. Killeen (SBN #84614)
303 Potrero St., Suite 52 Santa Cruz, CA 95060 831-600-7017
October 29, November 5, 12, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004544 The following person(s) is(are) conducting business
as:
Unique Gal, 7224 N. Chris Ave., Fresno, CA 93720, County of Fresno Registrant:
Farrah Hassoun, 7224 N. Chris Ave., Fresno, CA 93720
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Farrah Hassoun, Owner Filed with the Fresno County Clerk on September 25, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of
another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004519 The following person(s) is(are) conducting business
as:
Rover Imaging, 1650 E. Shepherd Ave., Apt. 102, Fresno, CA 93720, County of Fresno
Registrant:
Joel Ortiz, 1650 E. Shepherd Ave., Apt. 102, Fresno, CA 93720 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 04/01/2019 This business is conducted by: an Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Joel Ortiz, Owner
Filed with the Fresno County Clerk on September 25, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004467 The following person(s) is(are) conducting business
as:
Laurel Grove Australian Labradoodles, 6822 E.
Braly Ave, Fresno, CA 93727, County of Fresno Registrant:
Michelle L. Barahona, 6822 E. Braly Ave., Fresno, CA 93727
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 06/01/2020 This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Michelle L. Barahona, Owner
Filed with the Fresno County Clerk on September 23, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004565 The following person(s) is(are) conducting business
as:
4 Seasons Solar Cleaning, 5569 N Polk Ave, Fresno, CA 93722, County of Fresno Registrant:
Jeremy Fortunato, 5569 N Polk Ave, Fresno, CA 93722
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and
correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Jeremy Fortunato, Owner
Filed with the Fresno County Clerk on September 28, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004513 The following person(s) is(are) conducting business
as:
her' Monastery Candle Library, 812 Sandra Ave., Sanger, CA 93657, County of Fresno
Registrant:
Nou Yang, 812 Sandra Ave., Sanger, CA 93657 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: n/a
This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Nou Yang, Owner Filed with the Fresno County Clerk on September 24, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq.,
Business and Professions Code).
New Filing
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004543 The following person(s) is(are) conducting business
as:
Chubby's Mobile Dog Grooming, 409 E. Marwood Ln., Fresno, CA 93720, County of Fresno Registrant:
Kimberly Deundian, 409 E. Marwood Ln., Fresno, CA 93720
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: n/a
This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Kimberly Deundian, Owner
Filed with the Fresno County Clerk on September 25, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
10/15, 10/22, 10/29, 11/5/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004470 The following person(s) is(are) conducting business
as:
Optimus Pet Grooming, 3461 W. Gettysburg Ave., Fresno, CA 93722, County of Fresno
Registrant: OPTIMUS PET GROOMING LLC, 3461 W. Gettysburg Ave., Fresno,