Page 14 - Mid Valley Times 3-11-21 E-edition

NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT District Office
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Unified School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the Contract to construct:
Bid No. 2013 Preschool Playground Installation
as per the specifications which may now be obtained electronically from our website at www.kcusd. com. Select Departments, Purchasing & Warehouse, and follow the link on the right of the page to Bid Opportunities.
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequalification pursuant to Public Contract Code section 20111.6.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5 to perform public work as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work.
Contract time for this project shall be (30) calendar days from the issuance of the Notice to Proceed, and liquidated damages for delay shall accrue.
Bids must be sealed and filed at the Educational Support Center at 1801 10th St, Reedley, CA 93654 by March 30, 2021 prior to 2:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted.
A mandatory pre-bid conference will be held on March 19, 2021, at 9:00 a.m. at Reedley High School, located at 740 W. North Avenue, Reedley CA 93654. Bidders not attending the pre-bid conference will be disqualified.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to substitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a Class “C-61” or “A” license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty-five Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid. The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Copies of the required rates are on file at the Owner’s business office and are available on request.
Advertise:1st Publication Date 2nd Publication Date
John G. Campbell, Superintendent
March 11, 2021 March 18, 2021
correct. (A registrant who declares as true information which he or she knows to be false is guilty of a crime.) Signature of Registrant /s/ Karley Hager
Print Name Karley Hager This statement was filed with the county clerk
of Tulare County on: February 24, 2021 Roland P Hill, County Clerk
By: Chelsi Walters, Deputy Clerk
March 11, 18, 25 & April 1, 2021
FICTITIOUS BUSINESS NAME STATEMENT FILE NO 2021-435
Advertise:1st Publication Date 2nd Publication Date
John G. Campbell, Superintendent
March 11, 2021 March 18, 2021
false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Dustin Cramer, Treas. of gen partner A3 Smart Home LP, by Safe GP DRE LLC, general partner
Filed with the Fresno County Clerk on 02/23/2021
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal,
March 11 & 18, 2021
before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code). New Filing
3/11, 3/18, 3/25, 4/1/21
FICTITIOUS BUSINESS NAME STATEMENT
File No. 2202110000928 The following person(s) is(are) conducting
March 11 & 18, 2021
5821 W. Vine Ave. Visalia, CA 93291 County of Tulare
Fictitious Business Name: Optisoft Systems
Registrant Address: Arshag, Inc.
5821 W. Vine Ave. Visalia, CA 93291
2021
FICTITIOUS BUSINESS NAME STATEMENT FILE NO 2021-293
NEW FILE
THE FOLLOWING PERSONS ARE DOING BUSINESS AS:
Fictitious Business Name Statement: Memory Lane Antiques and Collectibles
Street Address of the Principal Place of Business
139 S. L Street Dinuba, CA 93618 Tulare County
Mailing Address:
1022 E. Elizabeth Way Dinuba, CA 93618
Section 2328 of the UCC, Section 535 of the Penal Code and provisions of the Civil Code.
The undersigned, on behalf of Heritage Self Storage, 1885 E. Dinuba, Reedley, CA 93654 will sell at a public sale, by competitive bidding on Thursday, March 25, 2021 at www. storagetreasures.com, the following delinquent tenant’s items are described as misc., household items, and boxes and/or totes of contents unknown.
The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code). Renewal Filing
3/11, 3/18, 3/25, 4/1/21
NOTICE OF PETITION TO ADMINISTER ESTATE OF Samuel Duran
CASE NO. 21CEPR00233
To all heirs, beneficiaries, creditors, and persons
If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may
I declare that all the
information in this
statement is true and
correct. (A registrant
who declares as true
any material matter
pursuant to Section
17913 of the Business
and Professions Code
that the registrant
knows to be false is
guilty of a misdemeanor FICTITIOUS BUSINESS punishable by a fine not NAME STATEMENT
Scarborough, Trustee of The Millard Family Rev. Trust
1022 E. Elizabeth Way Dinuba, CA 93618 Susan Elaine Carranza, Trustee of The Millard Family Rev. Trust
1022 E. Elizabeth Way Dinuba, CA 93618 JesseRayNavarro, Trustee of The Millard Family Rev. Trust 1022 E. Elizabeth Way Dinuba, CA 93618 This business is conducted by: A Trust The registrant commenced to transact business under the fictitious business name above listed above on: n/a
1234
Schular, Misty M.
et seq., Business and Professions Code). New Filing
3/11, 3/18, 3/25, 4/1/21
FICTITIOUS BUSINESS NAME STATEMENT
File No. 2202110000852 The following person(s) is(are) conducting
business as:
Apps All Around, 1077 E. Herndon Avenue, Fresno, CA 93710 County of FRESNO Mailing Address:
19111 North Dallas Parkway, Suite 165, Dallas, TX 75287 Registrant:
TGI Friday’s Inc., 19111 North Dallas Parkway, Suite 165, Dallas, TX 75287
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A.
This business is conducted by: a Corporation
Articles of Incorporation: LLC/AI No 284724
This Statement has been executed pursuant to section 17919 of the Business and Professions code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1000.)
TGI Friday’s Inc.
S/ Jennifer Rote, Vice President,
Filed with the Fresno County Clerk on 02/23/2021.
A New Fictitious Business Name Statement must be filed
CT., STE 100, WEST SACRAMENTO, CA 95605 County of YOLO Mailing Address:
710 RIVERPOINT CT., STE 100, WEST SACRAMENTO, CA 95605
estate, or both, of: Samuel Duran
A Petition for Probate has been filed by: Gabriel D. Jimenez in the Superior Court of California, County of Fresno
The Petition for probate
in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal
BUSINESS AS:
Fictitious Business Name Statement: Just by Chance Cleaning
Street Address of the Principal Place of Business
42859 Road 52, Unit A
dollars ($1,000).)
Entity Name Arhsag, Inc.
Signature /s/ Richard Tamouzian
Print Name Richard Tamouzian, President
I hereby certify that this copy is a correct copy of the original statement on fileinmyoffice.
Roland P. Hill, County Clerk
By: Ruth Meneses, Deputy
This statement was filed with the County Clerk
of Tulare on: February 16, 2021
March 11, 18, 25 & March 4, 2021
The Following Person is Conducting Business as New First Filing
Fictitious Business Name:
Big G Towing
2646 E. Jefferson Ave. Fresno, CA 93725 County of Fresno
(559) 960-5975 FullNameofRegistrant Lino Gomez III
2646 E. Jefferson Ave. Fresno, CA 93725
This business conducted by: an individual Registrant has not yet commenced to transact business under the Fictitious Business Name(s) listed above n/a Registrant’s Name Lino Gomez III, Owner
Filed with the Fresno County Clerk on: February 12, 2021 Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk March 4, 11, 18 & April 1, 2
LIFE’S MILESTONES
ENGAGEMENTS
WEDDING ANNOUNCEMENTS
WEDDING ANNIVERSARY
CALL FOR PRICE
BIRTH ANNOUNCEMENTS
CARD OF THANKS IN MEMORY
$13.50
PER COLUMN INCH
Gomez, John A
1458
M a g d a l e n o , A r t u r o Unit B701
Unit 1431 Juarez, Rosa A
Unit Moreno, Jose Unit 1332
Unit
Thursday, March 11, 2021 | A14| Mid Valley TiMes PUBLIC NOTICES
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT District Office
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Unified School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the Contract to construct:
Bid No. 2014 Reedley High School Softball Bleachers
as per drawings and specifications which may now be obtained electronically from our website at www. kcusd.com. Select Department, Purchasing & Warehouse, and follow the link on the right of the page to Bid Opportunities.
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequalification pursuant to Public Contract Code section 20111.6.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5 to perform public work as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work.
Bids must be sealed and filed at the Educational Support Center at 1801 10th St, Reedley, CA 93654 by March 30, 2021 prior to 2:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted.
A mandatory pre-bid conference call will be held on Friday, March 19, 2021, at 10:00 a.m. The conference call phone number can be found in the Instructions to Bidders. Bidders not attending the pre-bid conference call will be disqualified.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to substitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a Class “C-61” license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty-five Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid. The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Copies of the required rates are on file at the Owner’s business office and are available on request.
March 4, 11, 18 & April 1, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000845
The Following Person is Conducting Business as New First Filing
Fictitious Business Name:
The Lounge
4722 E. Normal Fresno, CA 93703 County of Fresno
(559) 779-0049
Full Name of Registrant Aruma Romero
4722 E. Normal
Fresno, CA 93703
This business conducted by: an individual Registrant has not yet commenced to transact business under the Fictitious Business Name(s) listed above n/a Registrant’s Name Aruma Romero
Filed with the Fresno County Clerk on: February 23, 2021 Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk March 4, 11, 18 & April 1, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110001058
The Following Person is Conducting Business as New First Filing
Fictitious Business Name:
MZA Flooring
2328 N. San Pablo Ave., Apt. A
Fresno, CA 93704 County of Fresno
(559) 903-0572
Full Name of Registrant Jose Luiz Mendoza 2328 N. San Pablo Ave., Apt. A
Fresno, CA 93704
This business conducted by: an individual Registrant has not yet commenced to transact business under the Fictitious Business Name(s) listed above 3/8/2021
Registrant’s Name Jose Luis Mendoza, Owner Filed with the Fresno County Clerk on: March 8, 2021
Brandi L. Orth, County Clerk
By: Martha Garcia, Deputy County Clerk March 4, 11, 18 & April 1, 2021
business as:
MichaelAllen Solis,Frida UnitState,orcommonlawCLARK PACIFIC,whomayotherwisebewanttoconsultwithanTHEFOLLOWING
Full Name of Registrant
NEW FILE
(See Section 14411 710 RIVERPOINT interestedinthewillor attorneyknowledgeable PERSONSAREDOING
toexceedonethousandFileNo.2202110000687
I declare that all the
information in this NAME STATEMENT
FICTITIOUS BUSINESS NAME STATEMENT
statement is true and correct. (A registrant who declares as true information which he or she knows to be false is guilty of a crime.) Signature of Registrant /s/ Michael A. Scarborough
Print Name Michael A. Scarborough
This statement was filed with the county clerk
of Tulare County on: February 11, 2021 RolandPHill,County Clerk
By: Maegan Hansen, Deputy Clerk
March 4, 11, 18 & 25, 2021
PublicNotice
NOTICE OF PUBLIC SALE OF PERSONAL PROPERTY
NOTICE IS HEREBY GIVEN that the undersigned intends to sell the personal property described below to enforce a lien imposed on said property pursuant to Sections 21700- 21716oftheBusiness and Professions Code,
File No. 2202110000824 The following person(s) is(are) conducting
business as:
AAA Smart Home, 1277 Treat Blvd., Suite 1000, Walnut Creek, CA 94597, County of Fresno
Registrant:
A3 Smart Home LP, 1277 Treat Blvd., Suite 1000, Walnut Creek, CA 94597
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 09/15/2019 This business is conducted by: Limited Partnership
Articles of Incorporation: 199818200002
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information,
n/a
I declare that all the information in this statement is true and correct. (A registrant who declares as true information which he or she knows to be false is guilty of a crime.) Signature of Registrant /s/ Chancey Mae Thompson
Print Name Chancey Mae Thompson
This statement was filed withthecountyclerkof Tulare County on: March 3, 2021
Roland P Hill, County Clerk
By: Maegan Hansen, Deputy Clerk March11,18,25&April 1, 2021
FICTITIOUS BUSINESS NAME STATEMENT FILE NO 2021-0000318
FIRST FILING
Began Transacting Business: 4/1/2003 Statement Expires On: 2/16/2026 BusinessIsConducted By:Corporation Business Address:
The Following Person is Conducting Business as New First Filing
Fictitious Business Name:
CenCal Trans, LLC CenCal Transportation
1263 Oak Ave.
Clovis, CA 93611 County of Fresno
(559) 349-3675
Full Name of Registrant CenCal Trans LLC 1263 Oak Ave.
Clovis, CA 93611 (IfcorporationorLLC, print number listed on Articles of Incorporation) 202103910798
This business conducted by: limited liability company Registranthasnotyet commenced to transact business under the Fictitious Business Name(s) listed above n/a Registrant’s Name David . Wilson, Member
Filed with the Fresno County Clerk on: February 25, 2021 Brandi L. Orth, County Clerk
OBITUARIES INCLUDES PHOTO AND SENTIMENT
1112
Purchases must be paid in cash.
All purchased items sold as is, where is, and mustberemoved.Sale subject to cancellation in the event of settlement between owner and obligated party.
Dated this 10th day of March 2021 Auctioneer: www. storagetreasures.com, (480) 397-6503
March 11 & 18, 2021
FICTITIOUS BUSINESS
requests that Gabriel D.
CLARK PACIFICJimenezbeappointedasofestateassetsorofanyReedley,CA93654
Registrant:
PRECAST, LLC, 710 personalrepresentative petitionoraccountas TulareCounty
RIVERPOINT CT., STE 100, WEST SACRAMENTO, CA 95605
DONALD G. CLARK CORPORATION, 710 RIVERPOINT CT., STE 100, WEST SACRAMENTO, CA 95605
ROBERT E. CLARK CORPORATION, 710 RIVERPOINT CT., STE 100, WEST SACRAMENTO, CA 95605
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 01/01/1963. This business is conducted by: a General Partnership
Articles of Incorporation: LLC/AI No C1612301 This Statement has been executed pursuant to section 17919 of the Business and Professions code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1000.)
S/ DONALD G. CLARK, Filed with the Fresno County Clerk on 02/26/2021.
A New Fictitious Business Name Statementmustbefiled before the expiration.
to administer the estate of the decedent.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not granttheauthority.
A hearing on the petition will be held in this court as follows:
Date: April 8, 2021
Time: 9:00 a.m.
Dept.: 303 Addressofcourt:1130 “O” Street, 3rd Floor, Fresno CA 93721, B.F. Sisk Courthouse
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Yourappearancemay beinpersonorbyyour attorney.
provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for Petitioner: Curtis D. Rindlisbacher, Esq.
Baker, Manock & Jensen, PC
5260 N. Palm Ave., Ste. 421
Fresno, CA 93704 559-432-5400
February 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT FILE NO 2021-381
NEW FILE
THE FOLLOWING PERSONS ARE DOING BUSINESS AS:
Fictitious Business Name Statement: Hager Designs
Street Address of the PrincipalPlaceof Business
4280 Ave. 410 Dinuba, CA 93618 Tulare County
Full Name of Registrant Karley Marie Hager 4280Ave.410
Dinuba, CA 93618 This business is conducted by: An Individual
The registrant commenced to transact business under the fictitious business name above listed above on: 1/1/2020 Ideclarethatallthe informationinthis statement is true and
Full Name of Registrant Chancey Mae Thompson
42859 Road 52, Unit A Reedley, CA 93654 This business is conducted by: An Individual
The registrant
commenced to transact
business under the
fictitious business name
above listed above on: File No. 2202110000913
FRIDAY, NOON, By:DakotaThurston, WEEK PRIOR
Deputy County Clerk
TO PUBLICATION
$13.50
PER COLUMN INCH
DEADLINE: