Page 36 - Attachments 30-8-16

B Form of Contract
The Form of Contract will be the JCT Minor Works Building Contra2007. The following insertions and deletions are to be made in the Clause etc.
New Fourth Recital (see Amendment 1)
Fifth Recital (previously Fourth Recital)
Article 7
1.1 (see Amendment 1)
2.2
2.2 2.8 2.10
4.3 4.5
4.8.1
4.11 and Schedule 2 5.3.2
5.4A, 5.4B & 5.4C (see Amendment 1)
5.4A.l and 5.4B.1.2 7.2 Adjudication
Schedule 1 (paragraph 1) and Schedule 2 (paragraphs 1.1, 1.2, 1.5, 1.6, 2.1 and 2.2)
Schedule 1 (paragraph 2.1)
Subject
Construction Industry Scheme (CIS)
CDM Regulations Regulations apply Arbitration
CDM Planning Period
Date for Commencement of the Works
Date for Completion Liquidated damages Rectification Period
Percentage of the total value of work etc. Percentage of the total amount to be paid to the contractor
Supply of documentation for computation of amount to be finally certified
Contribution, levy and tax changes Contractor's insurance - injury to persons or property. Insurance cover (jor anyone occurrence or series of occurrences arising out of one event) occurrences arising out of one event)
Insurance of the Works etc. - alternative provisions
Percentage to cover professional fees
Nominator of Adjudicator
Base Date
Arbitration
Appointment of Arbitrator (and of any replacement)
3