Page 13 - Mid Valley Times 10-1-20 E-edition

Thursday, October 1, 2020 | B3 | Mid Valley TiMes PUBLIC NOTICES
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT
District Of ce
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Uni- ed School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for
accepted.
Mandatory pre-bid conference will be held on October 2, 2020, at 9:00 a.m. at Reedley High School, 740 W. North Avenue, Reed- ley, California, 93654 and Orange Cove High School, 1700 Anchor, Orange Cove, Califor- nia 93646. Bidders not attending one of the pre-bid conference will be disquali ed.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certi ed check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to sub- stitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in ac- cordance with the California Public Contract Code, providing for the licensing of contrac- tors. In accordance with Section 3300 of said Code, the bidder shall have a Class “B” li- cense and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty- ve Thousand Dollars ($25,000), bidder shall state the public works contrac- tor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid.
The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevail- ing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classi ed in an amount not less than the rates speci ed. Copies of the required rates are on le at the Owner’s business of ce and are available on request.
John G. Campbell, Superintendent September 24, October 1, 2020
the award of the Contract to construct:
Bid No. 2006 Reedley High School & Orange Cove High School Outdoor Learning Pavilions
as per drawings and speci cations which may now be obtained electronically from the Archi-
tect: Integrated Designs by SOMAM, Inc. 6011 N. Fresno St., Suite 130
Fresno, CA 93710
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequali cation pursuant to Public
Contract Code section 20111.6.
Public works projects shall be subject to com- pliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be quali ed to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and quali ed under Labor Code section 1725.5 to perform public work as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be quali ed to enter into, or engage in the performance of, any contract of public work (as de ned by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and quali ed under Labor Code section 1725.5 to perform public work. Contract Time shall be from October 19 to December 31, 2020 (73) calendar days, and liquidated damages for delay shall accrue. Bids must be sealed and led at the Educa- tional Support Center at 1801 10th St, Reed- ley, California 93654 by October 9, 2020 be- fore 9:00 a.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be
CUTLER-OROSI JOINT UNIFIED SCHOOL DISTRICT
PUBLIC AUCTION
October 9th 2020 at 9:00 A.M.
DISTRICT TRANSPORTATION AREA
41850 RD. 126
OROSI, CA 93647
THE DISTRICT WILL SELL SURPLUS GOODS AT PUBLIC AUCTION
ALL SALES ARE ON AN “AS IS BASIS” – ALL SALES FINAL (ITEMS ARE SOLD WITHOUT WARRANTIES OR GUARANTEES) ITEMS PURCHASED MUST BE PICKED UP IMMEDIATELY SALE ITEMS INCLUDE:
USED VEHICLES TRAILERS
OLD A/C UNITS CHAIRS
OLD COOLERS
OLD GOLF CARTS STUDENT DESKS
OLD FENCING
THE PUBLIC IS INVITED TO ATTEND
MANY OTHER ITEMS
TELL YOUR FRIENDS & FAMILY
EVERYONE LOVES AN AUCTION! CUTLER-OROSI JOINT UNIFIED SCHOOL DISTRICT 12623 Avenue 416 OROSI CA, 93647, TELEPHONE 528-4763 Raf Soghomonian, MOT Director
September 24, October 1, 2020
NOTICE OF PUBLIC HEARING
NOTICE IS HEREBY GIVEN that the Dinuba City Council will hold a PUBLIC HEARING to discuss:
Expenditures of the STATE COPS (Citizens Option for Public Safety) Grant awarded to Dinuba Police Department for $100,000 under As- sembly Bill 3229.
DATE:
TIME:
PLACE:
enced. If anyone wishes to correspond with the City Council in regard to this matter, please do so via email at info@dinuba.ca.gov by 5:00 pm on October 13, 2020. Please visit www.dinuba.org for more infor- mation concerning City Council meetings.
ALL INTERESTED PARTIES are invited to attend said HEARING to discuss the proposed use of grant funds.
FURTHER INFORMATION on the above notice may be viewed at the City Clerk’s of ce, City Hall, 405 E. El. Monte Way, by calling 591-5900.
ATTEST: City Clerk
October 1, 2020
October 13, 2020
6:30 p.m. or as soon as possible thereafter
Due to Covid-19 restrictions, the meeting will be teleconfer-
NOTICE OF INTENT TO APPOINT GOVERNING BOARD MEMBER
KINGS RIVER UNION SCHOOL DISTRICT
BE IT KNOWN THAT the Kings River Union School District had an insuf cient number of candidates le for the position of governing board member in Trustee Area 5 for the election to be held on No- vember 3, 2020. No persons have been nominated for one (1) gov- erning board member vacancy in Trustee Area 5 with a four-year term to expire on December 13, 2024.
In accordance with Education Code Section 5328, the governing board of the Kings River Union School District shall, at a meeting held prior to November 3, 2020, appoint one member in Trustee Area 5 for a term of four years.
Interested quali ed residents of the district are invited to make ap- plication at the school district of ce located at: 3961 Avenue 400, Kingsburg.
Dated: September 14, 2020By ___________________________ Clerk, Kings River Union School District October 1, 8, 2020
NOTICE OF PUBLIC LIEN SALE
Sale of abandoned property of: Storland of Reedley 776 North Haney Reedley Ca 93654 NOTICE IS HEREBY GIVEN that the undersigned will be sold to
the highest
bidder, pursuant to the California Self-Service Storage Facility Act,
(B & P Code 21700 et. Seq.) The following personal property including but
not limited to furniture, clothing, toys, tools, and/or other household goods
or miscellaneous items to-wit.
Unit 329-Celina Hinojosa Unit M115-Diana Zamora Unit 108-Christina Aguilar Unit 435-Albert Garcia Sale will be held by online auction at www. storagetreasures.com. Sale will begin at 9:00 am on Thursday September 24th, 2020 and end at 6:00 pm Saturday October 10th, 2020. All purchased goods are sold as is and must be removed 72 hours after the sale. Sale is subject to prior cancellation if settlement is reached between landlord and obligated party.
September 24, October 1, 2020
ADVERTISEMENT OF SALE NOTICE IS HEREBY GIVEN that the undersigned intends to sell the personal property described below pursuant to section 21702 of the Government Code. The undersigned will sell at public sale by competitive bidding on the 16th of October on the premises where said property has been stored and which are located at: Lock & Leave Self Storage, 1366 North Crawford Ave. Dinuba CA 93618. County of Tulare; State of California, sale
begins at 9:30 AM Agustine Calvillo
Dan or Joy Johnston Laura Padron
Thatcher Wong
Vanessa M. Gonzalez PROPERTY TO BE SOLD DESCRIBED AS: BICYCLE, SHOES, MOP BUCKET, CABINETS, YARD TOOLS, BOOTS,
DRESSER, CLOTHING, TOTES (CONTENTS UNKNOWN), ROTO TILLER, STUFFED ANIMALS, SHELVING, GOLF CLUBS, PALLETS, BOXES (CONTENTS UNKNOWN), BAGS (CONTENTS UNKNOWN), TRASH, MISCELLANEOUS HOUSEHOLD ITEMS, TOOL BOXES, WICKER FURNITURE, BLOWER, GLIDER, CHAIRS, ELECTRIC EQUIPMENT Purchases must be paid for in cash at the time of the auction. All purchased items are sold as is, where is, and must be removed at the time of sale. Sale is subject to cancellation in the event of settlement between owner and obligated party. This auction held with "reserve" dated this 16th of October.
A-Ward Auction
9411 Vintner Circle Diablo Grande, CA 95207 Joe Ward
Bond# MS237-04-79
Jeff Vercelli
Bond# MS153-13-71
October 1, 8, 2020
SUPERIOR COURT OF CALIFORNIA COUNTY OF FRESNO NOTICE TO CREDITORS [Probate Section 19050] Case No. 20CEPR00680 In re the Chakerian Family
Trust
Dated: January 27, 1995 By Adrienne F. Chakerian, Decedent
Notice is hereby given to the creditors and contingent creditors of the above- named decedent that all persons having claims against the decedent are required to file them with the Superior Court, at 1100 Van Ness Avenue, Fresno, California, 93724, and mail or deliver a copy to Randy M. Long, Attorney for the Trustee of the Trustee of the Survivor's Trust Chakerian Family Trust Dated: January 27, 1995, of which the decedent was the grantor, at 1756 11th Street, Reedley, California, 93654, within the later of four months after August 20, 2020, or if notice is mailed or personally delivered to you, 30 days after the date this notice is mailed or personally delivered to you,
or you must file a petition of file a late claim as provided in Section 19103 of the Probate Code. A claim form may be obtained from the court clerk. For your protection, you are encouraged to file your claim by certified mail, with return receipt requested. Date: August 7, 2020 Signed /s/ Randy M Long, Attorney for the Trustee of the Chakerian Family Trust Dated: January 27, 1995 1756 11th Street,
Reedley, CA 93654 September 17, 24,
October 1, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF Esther O. Fernandez CASE NO. 20CEPR00571 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: Esther O. Fernandez, Ester Ontiveros, Esther Ontiveros
Fernandez
A Petition for Probate has been filed by: Gilbert M. Fernandez in the Superior Court of California, County of Fresno.
The Petition for probate requests that Gilbert M. Fernandez be appointed as personal representative to administer the estate of the decedent.
The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should
not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: October 29, 2020 Time: 9:00 am
Dept.: 303
Address of court: 1130 "O" Street, Fresno, California 93721 B. F. Sisk Courthouse
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Petitioner: Gilbert M. Fernandez
271 Brehler Ave
Sanger, CA 93657 559-349-3263
September 24, October 1, 8, 2020
NOTICE OF PETITION TO ADMINISTER ESTATE OF JOHN LEE TARBELL, aka JOHN L. TARBELL, and JOHN TARBELL CASE NO. VPR050196 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: JOHN LEE TARBELL, aka JOHN L. TARBELL, and JOHN
TARBELL
A Petition for Probate has been filed by: CLAUDIA DENICE HERNANDEZ in the Superior Court of California, County of TULARE.
The Petition for probate requests that CLAUDIA DENICE HERNANDEZ be appointed as personal representative to administer the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: November 2, 2020 Time: 10:00 A.M.
Dept.: 7
Address of court: 221 South Mooney Blvd, Visalia, CA 93291 Probate
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Attorney for petitioner:
Gerald M. Tomassian 3419 W. Shaw Avenue Fresno, CA 93711 (559) 277-7300
October 1, 8, 15, 2020
ORDER TO SHOW CAUSE FOR CHANGE OF NAME PETITION OF Karen Emily Basmajian CASE NUMBER:
20 CE CG 02000
TO ALL INTERESTED
PERSONS:
Petitioner: Karen Emily Basmajian filed a petition with this court for a decree changing name as follows: Present Name
Karen Emily Basmajian Proposed Name
Karina Emily Basmajian THE COURT ORDERS that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.
NOTICE OF HEARING
a. Date: October 26, 2020 Time: 8:30 AM Dept.:404 b. The address of the court Civil Division
1130 O Street
Fresno CA 93724
A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this county: Mid Valley Times/ Reedley Exponent P.O. Box 432, Reedley, CA 93654 (559) 638-2244
Date: July 13, 2020 Signed /s/ Mark E. Cullers Judge of the Superior Court
September 17, 24, October 1, 8, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003842 The following person(s) is(are) conducting business
as:
Pour More Love, 1579 E Houston Ave, Fresno, CA 93720 County of FRESNO Registrant:
Korey C Jenkins, 1579 E Houston Ave, Fresno, CA 93720
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A.
This business is conducted by: an Individual
This Statement has been executed pursuant to section 17919 of the Business and Professions code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1000.)
S/ Korey C Jenkins,
Filed with the Fresno County Clerk on 08/18/2020.
A New Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003817 The following person(s) is(are) conducting business
as:
Love the Victim. Start the Healing, 1151 S. Chestnut Ave., Unit 139, Fresno, CA 93702, County of Fresno Registrant:
LOVE THE VICTIM...STOP THE HATE, INC., 1151 S. Chestnut Ave., Unit 139, Fresno, CA 93702 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Corporation
Articles of Incorporation: C4573147
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Denise M. Kesanen, President
Filed with the Fresno County Clerk on August 18, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
NEW FILING
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003790 The following person(s) is(are) conducting business
as:
Mobius Brass, 2209 Whiteash Ave., Clovis, CA 93619, County of Fresno Registrant:
MOBIUS RESEARCH GROUP INC., 2209 Whiteash Ave., Clovis, CA 93619
Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Corporation
Articles of Incorporation: C4617635
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Kyle Anderson, President Filed with the Fresno County Clerk on August 17, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003963 The following person(s) is(are) conducting business
as:
Social Spark, 11683 W. San Madele Ave., Fresno, CA 93711, County of Fresno
Registrant:
Cyndi Vanderhorst, 1683 W. San Madele Ave., Fresno, CA 93711 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: 07/14/2015 This business is conducted by: Individual
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Cyndi Vanderhorst Filed with the Fresno County Clerk on August 24, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New Filing
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010004045 The following person(s) is(are) conducting business
as:
ElementX, 516 W. Shaw, Ave., Suite 200, Fresno, CA 93704, County of Fresno
Registrant: AMARQUEZ.DESIGN, 516 W. Shaw, Ave., Suite 200, Fresno, CA 93704 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Corporation
Articles of Incorporation: C4193863
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Aaron Marquez,
President
Filed with the Fresno County Clerk on August 27, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New filing
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003724 The following person(s) is(are) conducting business
as:
River Oaks, 21409 Clovis Ave, Laton, CA 93242, County of Fresno Registrant:
Bobby Hearn, 21409 Clovis Ave, Laton, CA 93242 Brett Hearn, 21409 Clovis Ave, Laton, CA 93242 Registrant commenced to transact business under the Fictitious Business Name(s) listed above on: N/A
This business is conducted by: Joint Venture
This Statement has been executed pursuant to section 17919 of the Business and Professionals code.
I declare that all information in this statement is true and correct. (A registrant who declares as true information, false declarations are a misdemeanor punishable by a fine up to $1,000).
S/ Brett Hearn, General Partner
Filed with the Fresno County Clerk on August 13, 2020
A new Fictitious Business Name Statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under Federal, State, or common law (See Section 14411 et seq., Business and Professions Code).
New filing
9/10, 9/17, 9/24, 10/1/20
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003728 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Wise Soul, LLC 6405 E. Butler Ave. Fresno, CA 93727 Fresno County
Full Name of Registrant Wise Soul, LLC 6405 E. Butler Ave. Fresno, CA 93727 Registrant has not yet commenced to transact business under the Fictitious Business Name
listed above.
This business conducted by: LLC
Articles of Incorporation 20192251045
Registrant’s Name and Title Felipe Mercado, Manager Filed with the Fresno County Clerk on: August 13, 2020
A new statement must be filed prior to the expiration date.
Notice: this statement expires on August 12, 2025 Brandi L. Orth, County Clerk
By: Martha Garica, Deputy County Clerk
September 10, 17, 24, October 1, 2020
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202010003781 The Following Person is Conducting Business as
New Filing
Fictitious Business Name:
Rocking RB Ranch 33077 Wolverine Lane, Squaw Valley, CA 93675 Fresno County
Full Name of Registrant
Ryan T. Boyett 33077 Wolverine Lane, Squaw Valley, CA 93675 This business conducted
by: An Individual Registrant commenced to transact business under the Fictitious Business Name listed above on August 1, 2020
Registrant’s Name Ryan T. Boyett, Officer’s Title Owner Filed with the Fresno County Clerk on: August 17, 2020