Page 15 - Mid Valley Times 2-25-21 E-edition

Thursday, February 25, 2021 | A15| Mid Valley TiMes PUBLIC NOTICES
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT
District Office
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Unified School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the
Contract to construct:
Bid No. 2011 Reroof at Various Sites
as per the specifications which may now be obtained electronically from our website at www.kcusd. com. Select Departments, Purchasing & Warehouse, and follow the link on the right of the page to Bid Opportunities.
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequalification pursuant to Public Contract Code section 20111.6.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5 to perform public work as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work.
Contract Time shall be from April 1, 2021 to June 30, 2021 (91) calendar days, and liquidated damages for delay shall accrue.
Bids must be sealed and filed at the Educational Support Center at 1801 10th St, Reedley, CA 93654 by March 9, 2021, before 2:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted.
Mandatory pre-bid conferences to two sites will be held on February 26, 2021, at 9:00 a.m. at the Reedley High School main gym parking lot, located at 740 W. North Avenue, Reedley CA 93654. Bidders not attending the pre-bid conference will be disqualified.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to substitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a “C-39” license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty-five Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid.
The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Copies of the required rates are on file at the Owner’s business office and are available on request.
Advertise:1st Publication Date February 18, 2021 2nd Publication Date February 25, 2021
John G. Campbell, Superintendent
February 18 & 25, 2021
NOTICE TO BIDDERS
KINGS CANYON UNIFIED SCHOOL DISTRICT
District Office
1801 10th St,
Reedley, CA 93654
Notice is hereby given that Kings Canyon Unified School District (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of the
Contract to construct: Bid No. 2012 Carpet & Flooring at Various Sites
as per the specifications which may now be obtained electronically from our website at www.kcusd. com. Select Departments, Purchasing & Warehouse, and follow the link on the right of the page to Bid Opportunities.
The lowest bid shall be determined on the amount of the base bid. This Contract is not subject to prequalification pursuant to Public Contract Code section 20111.6.
Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5 to perform public work as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code. For all projects over Twenty-Five Thousand Dollars ($25,000), a contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1 (§§ 1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work.
Contract Time shall be from June 7, 2021 to August 4, 2021 (59) calendar days, and liquidated damages for delay shall accrue.
Bids must be sealed and filed at the Educational Support Center at 1801 10th St, Reedley, CA 93654 by March 9, 2021 before 1:00 p.m. on the clock designated by the Owner or its representative as the bid clock, after which time bids will be opened. No bid will be accepted by Owner after this time. Facsimile (FAX) copies of the bid will not be accepted.
Mandatory pre-bid conferences to multiple sites will be held on March 2, 2021, at 9:00 a.m. at the District Operations Center, located at 1500 I Street, Reedley CA 93654. Bidders not attending the pre-bid conference will be disqualified.
Bids must be accompanied by a bidder’s bond, cashier’s check, or certified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner.
Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum, as set forth in the Contract Documents.
The successful bidder will be allowed to substitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions.
The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a Class “C-15” license and shall maintain that license in good standing through Contract completion and all applicable warranty periods. For all projects over Twenty-five Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid. The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Copies of the required rates are on file at the Owner’s business office and are available on request.
Your appearance may be in person or by your attorney.
If you are a creditor or contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.
Petitioner: Olga L. Hernandez and Carmen J. Galvan
5686 E. Kaviland Ave. Fresno, CA 93727 559-960-8275
February 25, March 4 & 11, 2021
NOTICE OF PETITION TO ADMINISTER ESTATE OF Blanca Estela Carrasco, aka Blanca E. Carrasco and Blanca Carrasco, deceased.
CASE NO. VPR050427 To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: Blanca Estela Carrasco, aka Blanca E. Carrasco, and Blanca Carrasco, deceased
A Petition for Probate has been filed by: Veronica Jennifer Gomez in the Superior Court of California, County of Tulare
The Petition for probate requests that Veronica Jennifer Gomez be appointed as personal representative to administer the estate of the decedent.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: March 17, 2021 Time: 10:00 a.m.
642 S West ST
Tulare, CA 93274
Perez Guzman, Emma 642 S West ST
Tulare, CA 93274
Perez Guzman, Victor A 642 S West ST
Tulare, CA 93274
I declare that all the information in this statement is true and correct. (A registrant who declares as true any material matter pursuant to Section 17913 of the Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000).) Signature /s/ Victor Perez
Print Name Victor Perez I hereby certify that this copy is a correct copy of the original statement on file in my office. Roland P. Hill, County Clerk
By: Chelsi Walters, Deputy
This statement was filed with the County Clerk
of Tulare on: February 10, 2021
February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000416
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
Alfredo’s Lawn Service
4121 E. Holland Ave. Fresno, CA 93726 County of Fresno
Full Name of Registrant Alfredo Miguel Arendano 4121 E. Holland Ave. Fresno, CA 93726
This business conducted by: an individual Registrant commenced to transact business under the Fictitious Business Name listed above on 1/1/2021 Registrant’s Name
Alfredo Miguel, Owner Filed with the Fresno County Clerk on: January 28, 2021 Brandi L. Orth, County Clerk
By: Carlos Aguirre, Deputy County Clerk February 18, 25, March 4&11,2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000471
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
Scott Water Well Service Nerison Pump Service
1650 S Rainbow Ave. Sanger, CA 93657 County of Fresno
Full Name of Registrant Thomas P Krazan 1650 S Rainbow Ave. Sanger, CA 93657
This business conducted by: an individual Registrant commenced to transact business under the Fictitious Business Name listed above on n/a Registrant’s Name Thomas P Krazan, Sole Proprietor
Filed with the Fresno County Clerk on: February 1, 2021 Brandi L. Orth, County Clerk
By: Dakota Thurston, Deputy County Clerk February 18, 25, March 4&11,2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000455
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
Crystalz_At_Tiffanys
431 Morton Ave. Sanger, CA 93657 County of Fresno
Full Name of Registrant Christopher Meyer
431 Morton Ave. Sanger, CA 93657
Tiffany Meyer
431 Morton Ave. Sanger, CA 93657
This business conducted by: a married couple Registrant commenced to transact business under the Fictitious Business Name listed above on 1/1/2021 Registrant’s Name Christopher Meyer, Co-Owner
Filed with the Fresno County Clerk on: January 29, 2021
Brandi L. Orth, County Clerk
By: Cyan Edmisten, Deputy County Clerk February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000393
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
La Hacienda Banquet Hall LLC
1345 7th Street Sanger, CA 93657 County of Fresno
Full Name of Registrant
La Hacienda Banquet Hall LLC
1345 7th Street
Sanger, CA 93657
(If corporation or LLC, print number listed on Articles of Incorporation) 202021311034
This business conducted by: limited liability company
Registrant commenced to transact business under the Fictitious Business Name listed above on n/a Registrant’s Name Miguel A. Serrano, CEO Filed with the Fresno County Clerk on: January 26, 2021
Brandi L. Orth, County Clerk
By: Carlos Aguirre, Deputy County Clerk February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000267
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
Clovis Orthodontics
240 W. Shaw Ave., #110 Clovis, CA 93612 County of Fresno
Full Name of Registrant Sung Shyn, DDS, INC. 240 W. Shaw Ave., #110 Clovis, CA 93612
(If corporation or LLC, print number listed on Articles of Incorporation) C4675155
This business conducted by: a corporation Registrant commenced to transact business under the Fictitious Business Name listed above on 12/17/2020 Registrant’s Name Sung Shyn, President
Filed with the Fresno County Clerk on: January 19, 2021 Brandi L. Orth, County Clerk
By: Dakota Thurston, Deputy County Clerk February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000309
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
American Cleaning
2251 Magill Ave. Clovis, CA 93611
(559) 905-2374
County of Fresno
Full Name of Registrant Christopher Aaron De La Torre
2251 Magill Ave. Clovis, CA 93611 Brian Monique De La Torre
2251 Magill Ave.
Clovis, CA 93611
This business conducted by: a married couple Registrant commenced to transact business
under the Fictitious Business Name listed above on n/a Registrant’s Name Christopher & Briana De La Torre, Co-Owner/ Owner
Filed with the Fresno County Clerk on: January 21, 2021 Brandi L. Orth, County Clerk
By: Dakota Thurston, Deputy County Clerk February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000456
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
B4L Clothing Co.
1145 N. Ring Ave. Fresno, CA 93723 (559) 917-6313
County of Fresno
Full Name of Registrant David Serna
1145 N. Ring Ave. Fresno, CA 93723
This business conducted by: an individual Registrant commenced to transact business under the Fictitious Business Name listed above on n/a Registrant’s Name David Serna, Owner
Filed with the Fresno County Clerk on: January 29, 2021
Brandi L. Orth, County Clerk
By: Yvette Jamison, Deputy County Clerk February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT FILE NO 2021-284
NEW FILE
THE FOLLOWING PERSONS ARE DOING BUSINESS AS: Fictitious Business Name Statement:
Taqueria Hermanos Barrera
Street Address of the
Principal Place of Business
1500 N. Houston Ave. Visalia, CA 93291 Tulare County
Mailing Address:
1839 W. Connelly Ave. Visalia, CA 93291
Full Name of Registrant Taqueria Hermanos Barrera
1839 W. Connelly Ave. Visalia, CA 93291
This business is conducted by: A Limited Liability Company
The registrant commenced to transact business under the fictitious business name above listed above on: n/a
I declare that all the information in this statement is true and correct. (A registrant who declares as true information which he or she knows to be false is guilty of a crime.) Signature of Registrant /s/ Yensi Barrera Ventura
Print Name Yensi Barrera Ventura, Owner This statement was filed with the county clerk
of Tulare County on: February 10, 2021 Roland P Hill, County Clerk
By: Chelsi Walters, Deputy Clerk
February 18, 25, March 4 & 11, 2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000566
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
A-1 Equipment Rentals
42931 Road 52 Reedley, CA 93654 County of Fresno
Full Name of Registrant Yang Equipment Solutions, LLC
42931 Road 52 Reedley, CA 93654 (If corporation or LLC, print number listed on
Advertise:1st Publication Date 2nd Publication Date
John G. Campbell, Superintendent
February 18, 2021 February 25, 2021
Articles of Incorporation) 202032310117
This business conducted by: limited liability company
Registrant commenced to transact business under the Fictitious Business Name listed above on n/a Registrant’s Name Noemi Yanes, Member/ Manager
Filed with the Fresno County Clerk on: February 3, 2021 Brandi L. Orth, County Clerk
By: Cyan Edmisten, Deputy County Clerk February 18, 25, March 4&11,2021
FICTITIOUS BUSINESS NAME STATEMENT File No. 2202110000302
The Following Person is Conducting Business as New First Filing Fictitious Business Name:
Huddl Studio
3382 Crevasse Lane Clovis, CA 93618 County of Fresno
Full Name of Registrant Emily Puente
3382 Crevasse Lane Clovis, CA 93618 Steven Puente
3382 Crevasse Lane Clovis, CA 93619
This business conducted by: a married couple Registrant commenced to transact business under the Fictitious Business Name listed above on 10/17/2020 Registrant’s Name Emily Puente, Co-Owner
Filed with the Fresno County Clerk on: January 21, 2021 Brandi L. Orth, County Clerk
By: Carlos Aguirre, Deputy County Clerk February 18, 25, March 4&11,2021
NOTICE OF PETITION TO ADMINISTER ESTATE OF Margarita M. Galvan
February 18 & 25, 2021
CASE NO. 21CEPR00126
To all heirs, beneficiaries, creditors, and persons who may otherwise be interested in the will or estate, or both, of: Margarita Magaña Galvan
A Petition for Probate has been filed by: Olga L. Hernandez and Carmen J. Galvan in the Superior Court of California, County of Fresno
The Petition for probate requests that Olga L. Hernandez and Carmen J Galvan be appointed as personal representative to administer the estate of the decedent.
The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court as follows:
Date: March 24, 2021 Time: 9:00 a.m.
Dept.: 303
Address of court: 1130 “O” Street, 3rd Floor, Fresno CA 93721
If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing.